In the matter of:
Suo-moto proceeding initiated by the Commission for non-compliance of Commission’s directions issued vide Commission’s Order dated 06.07.2022 & 20.07.2022 pertaining to non-payment of penalty due w.r.t. delay in release of new LT connections.
AND In the matter of:
Managing Director,
Uttarakhand Power Corporation Ltd. (UPCL),
VCV Gabar Singh Urja Bhawan,
Kanwali Road, Dehradun
...........Respondent
15.09.2023
In the matter of:
Miscellaneous Petition challenging the Regulation No. 6.1 of the Uttarakhand Electricity Regulatory Commission (The Electricity Supply Code, Release of New Connections and Related Matters) Regulation, 2020, on the ground of the same being ultra-vires the mandatory provision of Section 56(1) of the Electricity Act, 2003 and the retrospective implication of the same, being used by UPCL in treating the Bill as a Bill cum Disconnection notice.
In the matter of:
M/s Uttaranchal Iron & Ispat Ltd.,
(Furnace Division), Plot No. 5, 6 & 7,
Industrial Area, Jashodharpur,
Kotdwar, District Pauri Garhwal
...........Petitioner AND In the matter of:
Managing Director,
Uttarakhand Power Corporation Ltd. (UPCL),
VCV Gabar Singh Urja Bhawan,
Kanwali Road, Dehradun
...........Respondent
07.08.2023
In the matter of:
Petition filed by M/s Bhilangana Hydro Power Ltd., under Section 86 read with Section 181 of
the Electricity Act, 2003 read with the Order dated 20.06.2023 passed by the Hon’ble
Uttarakhand High Court in WPMS 1829/2021 seeking for appropriate directions from
Commission to amend the UERC (Terms and Conditions of Intra-State Open Access
Regulations) 2015.
In the matter of:
M/s Bhilangana Hydro Power Ltd.
...........Petitioner AND In the matter of:
Power Transmission Corporation of Uttarakhand Ltd. (PTCUL)
...........Respondent
01.08.2023
In the matter of:
Petition under Section 62 and 86 of the Electricity Act, 2003 read with Regulation 50(6) of the Uttarakhand Electricity Regulatory Commission (Terms and Conditions for Determination of Multi Year Tariff) Regulations, 2018 & 2021 for recovery of under recovered energy charges due to shortfall in energy generation for reasons beyond the control of generating station during the FY 2020-21, FY 2021-22 and FY 2022-23 in respect of Budhil Hydro Power Project (BHEP).
AND In the matter of:
M/s Greenko Budhil Hydro Power Pvt. Ltd.
...........Petitioner & In the matter of:
Uttarakhand Power Corporation Ltd.
...........Respondent
03.07.2023
In the matter of:
Petition seeking to allow approximate cumulative capacity of 246.5 MW to be
allotted to eligible applicants against ground mounted solar power plants having
capacity size of 20/25/50/100/200 kW under the scheme Mukhyamantri Saur
Swarojgar Yojna at prefixed tariff of Rs. 4.49/kWh OR as per the gross generic tariff
for Solar PV plants decided by the Commission for FY 2023-24 whichever is higher
and subsequently fix such gross tariff for a tariff period of three years.
AND In the matter of:
Uttarakhand Renewable Energy Development Agency
...........Petitioner & In the matter of:
Uttarakhand Power Corporation Ltd. (UPCL),
VCV Gabar Singh Urja Bhawan,
Kanwali Road, Dehradun
...........Respondent
31.05.2023
In the matter of:
Suo-moto proceedings in the matter of request for seeking approval of revised payment terms for
release of gas payments.
In the matter of:
Uttarakhand Power Corporation Ltd. (UPCL)
M/s Sravanthi Energy Pvt. Ltd.
M/s Gama Infraprop (P) Ltd.
...........Respondents
13.04.2023
In the matter of:
Petition for Investment Approvals of Transmission Projects under UTSDIP Scheme under ADB
Funding for:
(1) Establishment of NABL, Accredited Oil Test Laboratory with associated building
and Transit hostel at 220 kV Substation, Ramnagar, Roorkee
(2) Establishment of NABL, Accredited Specialize Equipment Test laboratory (SETL)
with associated Office, Project Management and Monitoring Office buildings with
Transit hostel at 132 kV Substation, Kathgodam (Haldwani).
(3) 01 Set of Emergency Restoration System (ERS) for transmission lines.
(4) Extension/Augmentation of Existing 132/33 kV S/s Majra to 220/132 kV (2x160
MVA) GIS substation Majra and LILO of 220 kV Jhajra-IIP Harrawala Line at
proposed 220/33 kV GIS Substation Majra Dehradun through 220 kV underground
cable including Construction of Residential colony & Associated Development
works at 132 kV S/s Majra, Dehradun. AND In the matter of:
Power Transmission Corporation of Uttarakhand Ltd. (PTCUL)
...........Petitioner
13.04.2023
In the matter of:
Show Cause Notice-cum-Notice for Personal Hearing under Section 142 read with Section 149
of The Electricity Act, 2003, in the matter of non-compliance to Commission’s Orders/directions
with regard to delay in commissioning of 220 kV Baram Sub-station and its associated line. AND In the matter of:
Managing Director, Power Transmission Corporation of Uttarakhand Ltd. (PTCUL)
...........Petitioner
18.01.2023
In the matter of:
Petition filed by UJVN Ltd. Under Section 86(1)(c), (e), (f) and (k) read with Section 30 of the Electricity Act 2003 and Regulations 41(1) of UERC (Tariff and Other Terms for Supply of Electricity from Renewable Energy Sources and non-fossil fuel based Co-generating Stations) Regulations, 2018 seeking permission of the Commission to connect the Petitioner’s Suringad (5 MW) small hydro plant from 33/11 Darati S/s of UPCL.
AND In the matter of:
MManaging Director, UJVN Limited “UJJWAL”, Maharani Bag, GMS Road, Dehradun
...........Petitioner & In the Matter of:
1. Managing Director, Uttarakhand Power Corporation Ltd. (UPCL)
2. Managing Director, Power Transmission Corporation of Uttarakhand Ltd. (PTCUL)
3. M/s Himalaya Hydro Private Limited.
...........Respondents
03.01.2023
In the matter of:
Petition filed by Shri Chandrakant Singh Rawat (Innovative Solutions) seeking deemed generation claims due to late connectivity of its 500 kW Solar Power Plant with the grid and due to loss of generation because of outages/interruptions of more than 50 hours in a year. AND In the matter of:
Mr. Chandrakant Singh Rawat (Innovative Solutions),
188/1 Vasant Vihar, Opp. Electricity Office,
Dehradun.
...........Petitioner & In the Matter of:
1. Managing Director, UPCL, Victoria Cross Vijeta Gabar Singh Bhawan, Kanwali Road, Dehradun.
2. Executive Engineer, Electricity Distribution Division, Bhagwanpur, UPCL, Haridwar.
...........Respondents
03.01.2023
In the matter of:
PReconsider/Review Petition filed under Regulation 54 of UERC (Conduct of Business) Regulations, 2014 for removal of difficulty and review of the Order dated 22.09.2021 passed by UERC in the matter of Hon’ble APTEL Order dated 02.03.2020 in Appeal No. 18 of 2016 pertaining to 22.5 MW SHP of M/s Swasti Power Ltd. AND In the matter of:
Managing Director, UPCL, Victoria Cross Vijeta Gabar Singh Bhawan, Kanwali Road, Dehradun.
...........Petitioner & In the Matter of:
M/s Swasti Power Limited.
...........Respondent
23.12.2022
In the matter of:
Review/Reconsideration Petition filed by PTCUL under Regulation 54, 59 and 62 of the UERC (Conduct of Business) Regulations, 2014 r/w relevant provisions of Electricity Act 2003 for review of the order dated 14.10.2022 passed by the Commission in the matter of waiver of supervision charges for upgradation works of 220 kV D/C Mahuakhedaganj-Kashipur including LILO of SEPL by replacement of ACSR Zebra Conductor with high capacity ACCC Conductor as per UERC Order dated 05.03.2021 AND In the matter of:
Managing Director,
Power Transmission Corporation of Uttarakhand Limited (PTCUL),
Vidyut Bhawan, Saharanpur Road, Dehradun, Uttarakhand
...........Petitioner & In the Matter of:
M/s Sravanthi Energy Private Limited
Registered Office: 7th Floor, Block -B, Building Number 9, DLF Cyber City, DLF Phase III, Gurugram - 122 002, Haryana, India
...........Respondent
14.10.2022
In the matter of:
Petition seeking approval for increasing the Continuous Supply Surcharge as approved by the Commission in the Tariff Order dated 31.03.2022 for FY 2022-23. AND In the matter of:
Uttarakhand Power Corporation Ltd.
...........Petitioner
27.09.2022
In the matter of:
Petition filed by Shri Chandrakant Singh Rawat (Innovative Solutions) seeking deemed
generation claims due to late connectivity of its 500 kW Solar Power Plant with the grid
and due to loss of generation because of outages/interruptions of more than 50 hours in
a year. AND In the matter of:
Mr. Chandrakant Singh Rawat (Innovative Solutions),
188/1 Vasant Vihar, Opp. Electricity Office,
Dehradun.
...........Petitioner & In the Matter of:
1. Managing Director, UPCL, Victoria Cross Vijeta Gabar Singh Bhawan,
Kanwali Road, Dehradun.
2. Executive Engineer, Electricity Distribution Division,
Bhagwanpur, UPCL, Haridwar.
...........Respondent
24.08.2022
In the matter of:
Revision in Miscellaneous Charges as approved vide UERC’s Tariff Order dated
31.03.2022 for FY 2022-23. AND In the matter of:
Managing Director,
Uttarakhand Power Corporation Ltd. (UPCL),
VCV Gabar Singh Urja Bhawan,
Kanwali Road, Dehradun
...........Petitioner
24.08.2022
In the matter of:
Unplanned and irregular load shedding/curtailment of power by Uttarakhand
Power Corporation Limited during the period 01st of March 2022 to 30th June 2022
and being continued till date.
AND In the matter of:
M/s Galwalia Ispat Udyog (P) Limited,
Narayan Nagar Industrial Area,
Bajpur Road, Kashipur,
Udham Singh Nagar
...........Petitioner & In the matter of:
Managing Director,
Uttarakhand Power Corporation Ltd. (UPCL),
VCV Gabar Singh Urja Bhawan,
Kanwali Road, Dehradun
...........Respondent
24.08.2022
In the matter of:
Petition for seeking Removal of Difficulty in Implementation of Modified Time of Day Metering as
provided in Clause 6.1.3.5 of the Tariff Order dated 31.03.2022 for FY 2022-23.
In the matter of:
Uttarakhand Power Corporation Ltd.
...........Petitioner
23.08.2022
In the matter of:
Review Petition under Section 94 (1) (f) of the Electricity Act, 2003 (“Electricity Act”) read with
Regulation 54 of the UERC (Conduct of Business) Regulations, 2014 (“CBR Regulations, 2014”) seeking
review of the Order dated 22.06.2022 passed in Petition No. 14 of 2022 relating to Application for
approval of Draft Power Purchase Agreement for short term power purchase between Uttarakhand
Power Corporation Limited and M/s NTPC Vidyut Vyapar Nigam Ltd. (“NVVNL”).
In the matter of:
Uttarakhand Power Corporation Ltd.
...........Petitioner
27.07.2022
In the matter of:
Petition seeking grant of permission to connect 33 kV dedicated line from 15 MW Captive Solar Power Plant to the stepdown side of 132/33 kV switchyard of Kashi Vishwanath Steels Pvt. Ltd. at 33 kV level so that continuous support essentially required from the grid for reference voltage and frequency for synchronization of grid tied solar inverters be obtained.
In the matter of:
M/s Kashi Vishwanath Steels Pvt. Ltd.,
Narain Nagar Industrial Estate,
Bazpur Road, Kashipur-244713
...........Petitioner AND In the matter of:
(1) Uttarakhand Power Corporation Ltd. (UPCL),
VCV Gabar Singh Urja Bhawan, Kanwali Road, Dehradun
(2) Power Transmission Corporation of Uttarakhand Ltd. (PTCUL),
Vidyut Bhawan, Majra, Dehradun
(3) State Load Dispatch Centre (SLDC),
‘Vidyut Bhawan’, Majra, Dehradun
(4) Uttarakhand Renewable Energy Development Agency (UREDA)
...........Respondents
22.06.2022
In the matter of:
Suo-moto proceeding initiated under Section 142 and Section 146 read with
Section 149 of The Electricity Act, 2003 in the matter of violation of Section 12(b)
of the Electricity Act, 2003 and non-compliance of the directions of the
Commission issued vide its Tariff Order dated 29.03.2017.
AND In the matter of:
Managing Director,
Uttarakhand Power Corporation Ltd. (UPCL),
VCV Gabar Singh Urja Bhawan,
Kanwali Road, Dehradun &
Managing Director,
UJVN Limited,
“UJJWAL”, Maharani Bagh,
GMS Road, Dehradun
...........Respondents
22.06.2022
In the matter of:
Compliance of Reports/Plans/Procedures by the Distribution Licensee as per the
UERC (Distribution Code) regulations, 2018.
&
Suo-moto proceeding initiated by the Commission in the matter of misleading
submission made by the licensee against the compliance of Regulation 6.4 of the
UERC (Distribution Code) Regulations, 2018. AND In the matter of:
Managing Director,
Uttarakhand Power Corporation Ltd. (UPCL),
VCV Gabar Singh Urja Bhawan,
Kanwali Road, Dehradun
...........Respondent
07.06.2022
In the matter of:
Petition for review of the Commission’s Tariff Order dated 31.03.2022 on the ARR & Tariff Petition for
FY 2022-23 filed by UPCL.
In the matter of:
Uttarakhand Power Corporation Ltd.
...........Petitioner
20.05.2022
In the matter of:
Applicability of Rate Schedule RTS-4A: Agriculture Allied Activities in light of Hon’ble ATE Order dated 10.02.2022 in Appeal No. 339 of 2017 (UPCL Vs. UERC & M/s Flex Foods Ltd.). In the matter of:
M/s Flex Food Limited & Ors.
...........Petitioners AND In the matter of:
Uttarakhand Power Corporation Ltd.
...........Respondent
04.05.2022
In the matter of:
Petition for issuing necessary directions to UPCL to withdraw invoices issued against the Petitioner imposing 25% additional Temporary Supply Tariff and issue revised invoices under RTS-5 consumer category. In the matter of:
M/s Dhanashree Agro Products Pvt. Ltd.
...........Petitioner AND In the matter of:
Uttarakhand Power Corporation Ltd.
...........Respondent
19.04.2022
In the matter of:
Petition seeking extension of Control Period of the Benchmark Capital Cost & Generic Tariff as
declared by the Commission vide its Orders dated 11.05.2020, 30.09.2020 and 05.10.2020 till March,
2023 for installation of Solar PV Power Plants under the scheme of Mukhyamantri Saur Swarojgar
Yojna. In the matter of:
Uttarakhand Renewable Energy Development Agency (UREDA)
...........Petitioner AND In the matter of:
Uttarakhand Power Corporation Ltd.
19.04.2022
In the matter of:
Petition under Section 86(1)(e) and 86(1)(f) of the Electricity Act, 2003 seeking extension of time for
commissioning of the Solar generating project of the Petitioner. In the matter of:
Saraswati Devi
...........Petitioner AND In the matter of:
1. Uttarakhand Power Corporation Ltd.
2. Power Transmission Corporation of Uttarakhand Ltd.
3. Uttarakhand Renewable Energy Development Agency (UREDA)
19.04.2022
In the matter of:
Petition under Section 86(1)(e) and 86(1)(f) of the Electricity Act, 2003 seeking extension of time for
commissioning of the Solar generating project of the Petitioner. In the matter of:
M/s Parihar Construction
...........Petitioner AND In the matter of:
1. Uttarakhand Power Corporation Ltd.
2. Power Transmission Corporation of Uttarakhand Ltd.
3. Uttarakhand Renewable Energy Development Agency (UREDA)
19.04.2022
In the matter of:
Petition seeking utilization of 220 kV S/C dedicated transmission line of M/s Greenko Budhil HEP for
evacuating power from generating stations operating in Ravi Basin, Himachal Pradesh viz. SHP upto
31 MW and from 180 MW Bajoli Holi HEP upto 120 MW, using 2x315 MVA, 400/220/33 kV GIS
Pooling Station at Lahal, 220 kV S/C transmission line from Lahal connecting to 220 kV side of S/s at
Budhil HEP on the same Terms of Use (Alternative-A) as determined by the Commission vide Order
dated 04.12.20202 read with Order dated 30.06.2021. In the matter of:
1. Himachal Pradesh Power Transmission Corporation Ltd.
2. Himachal Pradesh State Electricity Board Ltd.
3. M/s Bajoli Holi Hydropower Pvt. Ltd.
...........Petitioners AND In the matter of:
1. Uttarakhand Power Corporation Ltd.
2. State Load Dispatch Centre (SLDC)
3. M/s Greenko Budhil Hydro Power Pvt. Ltd
...........Respondents
11.03.2022
In the matter of:
Petition under Section 86(1)(c), (e), (f) and (k) read with Section 30 of the Electricity Act 2003 and Regulations 41(1) of UERC (Tariff and Other Terms for Supply of Electricity from Renewable Energy Sources and non-fossil fuel based Co-generating Stations) Regulations, 2018 seeking permission of the Commission to connect the Petitioner’s Suringad (5 MW) small hydro plant from 33/11 Darati S/s of UPCL.
AND In the matter of:
Managing Director, UJVN Limited “UJJWAL”, Maharani Bag, GMS Road, Dehradun
...........Petitioner AND In the matter of:
1. Managing Director, Uttarakhand Power Corporation Ltd. (UPCL)
2. Managing Director, Power Transmission Corporation of Uttarakhand Ltd. (PTCUL)
3. M/s Himalaya Hydro Private Limited.
...........Respondent
11.03.2022
In the matter of:
Miscellaneous Petition, inter alia amongst other grounds concerning refund of MDC/LPS charges by illegal disconnection and for determining whether Minimum Demand Charges/ Late Payment Surcharge can be imposed, if power supply is disconnected u/s 56(1), without proper and clear 15 days’ notice u/s 181 r/w Section 50 of the Indian Electricity Act, 2003.
AND In the matter of:
M/s Uttaranchal Iron & Ispat Ltd., (Furnace Division), Plot No. 5, 6 & 7, Industrial area, Jashodharpur, Kotdwar, District Pauri Garhwal
...........Petitioner AND In the matter of:
Managing Director,
Uttarakhand Power Corporation Ltd.,
...........Respondent
23.02.2022
In the matter of:
Suo-moto proceedings initiated by the Commission in the matter of Noncompliance of the sub-Regulations 3.3.3(15), 3.3.3(16), 3.4.3(10) & 3.4.3(11) of the
UERC (The Electricity Supply Code, Release of New Connections and Related
matters) Regulations, 2020 in the matter of ‘Availability of Three Phase Energy
Meters’.
AND In the matter of:
Managing Director,
Uttarakhand Power Corporation Ltd.,
Victoria Cross Vijeta Gabar Singh Urja Bhawan,
Kanwali Road, Dehradun
...........Respondent
23.02.2022
In the matter of:
Suo-moto proceedings initiated by the Commission in the matter of noncompliance of the Commission’s directions issued vide letter dated 01.11.2021
pertaining to submission of Periodical Reports as per provisions of the
Regulations. & In the matter of:
Petition for extension of time for compliance of directions given by Hon’ble
Commission vide order dated 07.01.2020 passed in the matter of relaxing/waiving
or varying the provisions of UERC (Release of New LT Connections,
Enhancement and Reduction of Loads) Regulations, 2007 and UERC (Release of
New LT Connections, Enhancement and Reduction of Loads) Regulations, 2013
whereby the penalty was imposed in the matter of delay in release of new LT
service connections for the period of FY 2008-09 to FY 2018-19 and upto Aug-2019
and for suspension of Standards of Performance during the Covid-19 pandemic
period and accordingly waive the requirement of submitting various periodical
reports.
AND In the matter of:
Managing Director,
Uttarakhand Power Corporation Ltd.,
Victoria Cross Vijeta Gabar Singh Urja Bhawan,
Kanwali Road, Dehradun
...........Respondent
30.11.2021
In the matter of:
Petition under Section 79 of the Electricity Act, 2003, read with Article 13 (“Change in Law”) of the Power Purchase Agreement (“PPA”) dated 19.03.2012 executed between M/s Uttam Sugar Mills Ltd. and Uttarakhand Power Corporation Ltd.
In the matter of:
M/s Uttam Sugar Mills Ltd. ...........Petitioner AND In the matter of:
Uttarakhand Power Corporation Ltd.
...........Respondent
16.11.2021
In the matter of:
Petition seeking utilisation of 220 kV S/C Dedicated Transmission Line of M/s Greenko Budhil Hydro Electric Project for evacuating power from Generating Stations operating in Ravi Basin, Himachal Pradesh viz. Small Hydro Electric Projects of upto 26 MW and from Bajoli Holi HEP of upto 60 MW, using 2x315 MVA, 400/220/33 kV GIS Pooling Station at Lahal, 220 kV S/C transmission line (1.8 km) from Lahal connecting to 220 kV side of S/S at Budhil HEP on the same Terms of Use (Alternative-A) as determined by the Commission vide its Order dated 04.12.2020 read with Order dated 30.06.2021.
In the matter of:
1. Himachal Pradesh Power Transmission Corporation Ltd.
2. Himachal Pradesh State Electricity Board Ltd.
3. M/s Bajoli Holi Hydropower Pvt. Ltd. ...........Petitioners AND In the matter of:
1. Uttarakhand Power Corporation Ltd.
2. State Load Dispatch Centre (SLDC)
3. M/s Greenko Budhil Hydro Power Pvt. Ltd.
...........Respondents
12.10.2021
In the matter of:
Petition to Hon’ble Commission for resolution of matter pertaining to Deviation
Settlement Mechanism (“DSM”) Claim for 214 MW (225 MW ISO) for Phase I of
2x225 MW (450 MW ISO) Gas Based Combined Cycle Power Plant at Kashipur,
Uttarakhand to be filed by Sravanthi Energy Pvt. Ltd. under Section 86 of the
Electricity Act, 2003 read with Regulation 59 of the Uttarakhand Electricity
Regulatory Commission (Conduct of Business) Regulations, 2014 and the
Regulations 13 & 16 of UERC (Deviation Settlement Mechanism and Related
Matters) Regulations, 2017. & In the matter of:
Petition for DSM claim by SLDC for 107 MW from 225 MW Gas Based
Combined Cycle Power Plant, at Mahuakhedaganj, Kashipur, DistrictUdhamsinghnagar, Uttarakhand.
AND In the matter of:
M/s Sravanthi Energy Private Limited,
Registered Office: 7th Floor, Block-B, Building Number 9,
DLF Cyber City, DLF Phase III
Gurugram- 122002, Haryana, India ...............Petitioner & In the matter of:
M/s Gama Infraprop Pvt. Ltd.,
Registered Office: M-3 (First Floor),
Hauz Khas, Aurobindo Marg,
New Delhi- 110016, ...............Petitioner
AND
(1) Managing Director,
Uttarakhand Power Corporation Ltd. (UPCL),
VCV Gabar Singh Urja Bhawan, Kanwali Road, Dehradun
(2) Managing Director,
Power Trans. Corp. of Uttarakhand Ltd. (PTCUL),
Vidyut Bhawan, Majra, Dehradun
(3) Chief Engineer,
State Load Dispatch Centre (SLDC),
Vidyut Bhawan, Majra, Dehradun ...............Respondents
21.09.2021
In the matter of:
Review Petition for review of the Order dated 11.06.2021 passed by the Commission in Petition
No. 21 of 2020 in accordance with Section 94(f) of the Electricity Act, 2003 read with Section 114 &
Order 47 of the Civil Procedure Code, 1908.
In the matter of:
Sh. Digambar Singh Bisht ...........Petitioner AND In the matter of:
1. Uttarakhand Power Corporation Ltd. (UPCL)
2. Uttarakhand Renewable Energy Development Agency (UREDA)
3. Sh. Dhirendra Singh Rawat
...........Respondent
14.09.2021
In the matter of:
Hon’ble APTEL’s Judgement dated 02.03.2020 in Appeal No. 18 of 2016.
In the matter of:
M/s Swasti Power Ltd ...........Petitioner AND In the matter of:
Uttarakhand Power Corporation Ltd. (UPCL) ...........Respondent
07.09.2021
In the matter of:
Petition seeking adjustment of tariff for Vanala Small Hydro Power Project (15 MW) unit of M/s Him Urja Pvt. Ltd. in terms of the directions contained in Order of the Commission dated 08.07.2016 and also as per Section 61 an 62 of the Electricity Act, 2003, read with Regulation 16(3) & 25 of UERC (Tariff and other terms for Supply of Electricity from Renewable Energy Sources and non-fossil fuel based Co-generating Stations) Regulation, 2010, as amended from time to time and Regulation 3 & 4 (4) of the UERC (Terms and Conditions for Truing Up of Tariff) Regulations, 2008.
In the matter of:
M/s Him Urja Pvt. Ltd. ...........Petitioner AND In the matter of:
Uttarakhand Power Corporation Ltd. (UPCL) ...........Respondent
28.07.2021
In the matter of:
Hon’ble APTEL’s Judgement dated 02.03.2020 in Appeal No. 18 of 2016.
In the matter of:
M/s Swasti Power Ltd. ...........Petitioner AND In the matter of:
Uttarakhand Power Corporation Ltd. (UPCL) ...........Respondent
15.06.2021
In the matter of:
PPetition under Section 86(1) (c), (f) and (k) read with Section 30, Section 39(2) (c), Section 40(a) and
Section 42(1) of Electricity Act, 2003 seeking directions to Respondents to ensure efficient and
effective evacuation of power from the Petitioner’s Motighat (5MW) and Tanga (5 MW) small hydro
plants using 33/11 kV Darati Sub-station.
&
Interlocutory Application seeking directions to the Respondent No. 1 to maintain status quo qua
33/11 kV Darati Sub-station, thereby directing exclusive connectivity of the Petitioner’s SHP’s as well
as exclusive evacuation of power from the SHPs of the Petitioner, through 33/11 kV Darati substation until final disposal of the instant Petition.
In the matter of:
M/s Himalaya Hydro Private Limited. ...........Petitioner
AND In the matter of:
UUttarakhand Power Corporation Ltd. (UPCL) ..... Respondent No. 1
Power Transmission Corporation Of Uttarakhand Ltd. (PTCUL) ..... Respondent No. 2
UJVN Ltd. ..... Respondent No. 3
23.03.2021
In the matter of:
Petition under Section 62 and 86 of the Electricity Act, 2003 read with Regulation 1(3), 11(1) and
12 of the Uttarakhand Electricity Regulatory Commission (Terms and Conditions for
Determination of Multi Year Tariff) Regulations, 2018, for necessary directions to UPCL for release
of interest on delay in payments of its energy invoices for the FY 2018-19 & FY 2019-20.
In the matter of:
M/s Sravanthi Energy Pvt. Ltd. ...........Petitioner
AND In the matter of:
Uttarakhand Power Corporation Ltd. (UPCL)........... ...Respondent
12.03.2021
In the matter of:
Interlocutory Application seeking directions to the Respondent No. 1 to maintain status quo
qua 33/11 kV Darati Sub-station, thereby directing exclusive connectivity of the Petitioner’s
SHP’s as well as exclusive evacuation of power from the SHPs of the Petitioner, through 33/11
kV Darati sub-station until final disposal of the instant Petition.
In the matter of:
M/s Himalaya Hydro Private Limited. ...........Petitioner
AND In the matter of:
Uttarakhand Power Corporation Ltd. (UPCL)........... ...Respondent
09.03.2021
In the matter of:
Petition for seeking carry forward of expected surplus of 320.62 MU (non-solar) and expected
deficit of 110.28 MU (Solar) Renewable Purchase Obligation of FY 2020-21 as per the provisions of
UERC (Compliance of Renewable Purchase Obligation) Regulation, 2010.
In the matter of:
Uttarakhand Power Corporation Ltd. (UPCL) ...........Petitioner
AND In the matter of:
Uttarakhand Renewable Energy Development Agency
...Respondent
09.03.2021
In the matter of:
Repeated violation of Regulation 40 of CBR, clause 11 of licence conditions and
directions of the Commission issued in its various orders by UPCL.
& In the matter of:
Application seeking approval of Uttarakhand Electricity Regulatory
Commission (UERC) for investment on the work of construction of 10 nos. 33/11
KV GIS Substations under Integrated Power Development Scheme (IPDS)
Project of Ministry of Power, Govt. of India.
AND In the matter of:
Uttarakhand Power Corporation Ltd.,
Victoria Cross Vijeta Gabar Singh Urja Bhawan,
Kanwali Road, Dehradun
......Petitioner
05.01.2021
In the matter of:
Petition for recovery of charges collected by UJVN Ltd. for supply of electricity
made to the consumers of the State of Uttarakhand.
AND In the matter of:
Uttarakhand Power Corporation Ltd.,
Victoria Cross Vijeta Gabar Singh Urja Bhawan,
Kanwali Road, Dehradun
.....Petitioner
AND In the matter of:
UJVN Limited,
“UJJWAL”, Maharani Bagh,
GMS Road, Dehradun
.....Respondent
22.12.2020
In the matter of:
Petition under Section 86 (1)(a), Section 86(1)(f) read with Section 61(d) seeking directions to State
Load Despatch Centre of Uttarakhand to consider Scheduled Capacity as the Declared Capacity in
accordance with Section 32(2)(a) of the Electricity Act, 2003.
In the matter of:
M/s Greenko Budhil Hydro Power Pvt. Ltd.
...............Petitioners AND In the matter of:
State Load Despatch Centre
Uttarakhand Power Corporation Ltd.
...............Respondents
22.12.2020
In the matter of:
To grant permanent connectivity for 214MW (225 MW ISO) for Phase II of SEPL Power Project
without any state transmission charges/losses upto Intra-State connection point (Kashipur 400
KV station) and permission for upgradation of 220 KV transmission line (Double Ckt.)
Mahuakheraganj S/s to Kashipur S/s at the cost of SEPL.
In the matter of:
M/s Sravanthi Energy Private Limited
...............Petitioners AND In the matter of:
Power Transmission Corporation of Uttarakhand Ltd. (PTCUL).
...............Respondents
27.10.2020
In the matter of:
Revision of Order dated 23.07.2020 passed by the District Magistrate, Haridwar, in the matter of
payment of compensation of Rs. 2,35,549/- for damage to trees and Rs. 55,080/- for use of land
ignoring the mandate of law as enshrined in works of Licensee Rules 2006.
In the matter of:
1. Shri Hitler Saini, S/o Late Shri Satish Kumar,
2. Shri Ajay Sani S/o Late Shri Satish Kumar
3. Shri Rajkumar S/o Late Shri Satish Kumar
4. Shri Vishwadeep S/o Late Shri Satish Kumar
5. Smt Vedwati W/o Late Shri Satish Kumar
...............Petitioners AND In the matter of:
1. The Executive Engineer, Power Transmission Corporation of Uttarakhand Ltd.,
220 kV Line Piran Kaliyar, Office, 26, Civil Line, Roorkee.
2. The District Magistrate, Haridwar.
...............Respondents
27.10.2020
In the matter of:
Revision of Order dated 23.07.2020 passed by the District Magistrate, Haridwar, deciding
Khasra No. 44 situated at Village Dheer Majara, Ahatmaal, Tehsil Bhagwanpur as the land
belonging to Gram Sabha and payment of compensation of Rs. 1,91,325 to the Gram Sabha.
In the matter of:
1. Shri Chandra Kiran S/o Shri Jagpal Singh
2. Shri Jagpal Singh S/o Late Shri Malhu Ram
...............Petitioners AND In the matter of:
The Executive Engineer, Power Transmission Corporation of Uttarakhand Ltd.,
220 kV Line Piran Kaliyar, Office, 26, Civil Line, Roorkee-247667
2. The District Magistrate, Haridwar-249401
3. Gram Pradhan, Gram Sabha, Hallu Majra, Tehsil Bhagwanpur,
District Haridwar
...............Respondents
13.10.2020
In the matter of:
Petition for extension of time for compliance of directions given by Hon’ble
Commission vide order dated 07.01.2020 passed in the matter of relaxing/waiving
or varying the provisions of UERC (Release of New LT Connections,
Enhancement and Reduction of Loads) Regulations, 2007 and UERC (Release of
New LT Connections, Enhancement and Reduction of Loads) Regulations, 2013
whereby the penalty was imposed in the matter of delay in release of new LT
service connections for the period of FY 2008-09 to FY 2018-19 and upto Aug-2019
and for suspension of Standards of Performance during the COVID-19 pandemic
period and accordingly waive the requirement of submitting various periodical
reports.
AND In the matter of:
Uttarakhand Power Corporation Ltd.,
Victoria Cross Vijeta Gabar Singh Urja Bhawan,
Kanwali Road, Dehradun
.....Petitioner
13.10.2020
In the matter of:
Petition for issuing necessary directions for fixing the electricity rate as per the FY 2015-16 for the
allocated Solar Power Plants with respect to the advertisement date 01.01.2016 published by
UREDA in FY 2015-16 and 40% additional tariff for the Solar PV plants installed in the hilly terrain
of Uttarakhand.
In the matter of:
Sh. Dhirender Singh Rawat
Sh. Digamber Singh Bisht
...............Petitioners AND In the matter of:
Uttarakhand Power Corporation Ltd. (UPCL)
Uttarakhand Renewable Energy Development Agency (UREDA)
...............Respondents
13.10.2020
In the matter of:
Application seeking approval of the Commission on the Draft Power Purchase Agreement to be
executed between Uttarakhand Power Corp. Ltd. and Uttarakhand Project Development &
Construction Corp. Ltd. (UPDCC Ltd.).
In the matter of:
Uttarakhand Power Corporation Ltd. (UPCL)
.....Petitioner AND In the matter of:
M/s Uttarakhand Project Development & Construction Corp. Ltd.
.....Respondent
25.08.2020
In the matter of:
Application seeking approval of the Commission for investment on Under
grounding of HT & LT Electrical Networks in Haridwar Town under IPDS
Program- a flagship program of Ministry of Power under Govt. of India (GoI).
AND In the matter of:
Uttarakhand Power Corporation Ltd.,
Victoria Cross Vijeta Gabar Singh Urja Bhawan,
Kanwali Road, Dehradun
.....Petitioner
18.08.2020
In the matter of:
Petition for development of 2 MW Solar Project located at Birpur, Dehradun which is under
progress and to be connected at 33/11 kV Anarwala (MRS) Dehradun Cantt, Permission for
connecting 2 MW Plant output to the 33/11 kV Grid of UPCL at Anarwala may be granted on Net
Metering basis under Regulation 51 and 52 of RE Regulations, 2018.
In the matter of:
Garrison Engineer, Military Engineer Services (MES), Dehradun ...........Petitioner
AND
Uttarakhand Power Corporation Ltd. (UPCL)
Uttarakhand Renewable Energy Development Agency (UREDA)
18.08.2020
In the matter of:
Petition seeking increase in ceiling limit of 1 MW applicable to grid connected rooftop and solar
power plants to 2 MW under RE Regulations, 2018 for net metering arrangement.
In the matter of:
Garrison Engineer, Military Engineer Services (MES), Roorkee ...........Petitioner
AND
Uttarakhand Power Corporation Ltd. (UPCL)
Uttarakhand Renewable Energy Development Agency (UREDA)
18.08.2020
In the matter of:
Petition to extend the control period of the benchmark capital cost & generic tariff as declared by
the Commission vide its order dated 11.05.2020, upto March 2022 for upcoming 10,000 nos. Solar
PV Power Plants of capacity 25KWp each (cumulative capacity of 250 MW).
In the matter of:
Uttarakhand Renewable Energy Development Agency ...........Petitioner
AND
Uttarakhand Power Corporation Ltd. (UPCL)
14.08.2020
In the matter of:
Application for determination of Term of use for Utilization of 220 kV S/c Dedicated
Transmission Line of M/s Greenko Budhil Hydro Electrical Project for evacuating power from
Generating Station operating in Ravi Basin, Himachal Pradesh viz. Small Hydro Electric Project
of up to 26 MW by connecting 2x315 MVA 400/220/33 kV GIS Pooling Station at Lahal,
Himachal Pradesh to 220 kV side of S/S at Budhil HEP through a 220 kV S/C transmission line
(1.8 km) from Lahal to Budhil.
In the matter of:
UHimachal Pradesh Power Transmission Corporation Ltd. ...........Petitioner
Himachal Pradesh State Electricity Board Ltd. ...........Petitioner
AND
Uttarakhand Power Corporation Ltd. ...........Respondent No. 1
State Load Dispatch Centre (SLDC) ...........Respondent No. 2
M/s Greenko Budhil Hydro Power Pvt. Ltd.. ...........Respondent No. 3
29.05.2020
In the matter of:
Petition for recovery of charges collected by UJVN Ltd. for supply of electricity
made to the consumers of the State of Uttarakhand.
AND In the matter of:
Uttarakhand Power Corporation Ltd. (UPCL),
VCV Gabar Singh Urja Bhawan,
Kanwali Road, Dehradun
…Petitioner &
UJVN Limited,
“UJJWAL”, Maharani Bagh,
GMS Road, Dehradun
…Respondent
14.02.2020
In the matter of:
Representation/Petition under Section 67(4) of the Electricity Act, 2003, in the
matter of dispute regarding release of connection by UPCL to an individual
consumer connected to the electrical network owned & operated by a
developer/builder/Residential Welfare Association.
AND In the matter of:
M/s Hero Reality Pvt. Ltd.,
264, Ground Floor, Okhla Industrial Estate, Phase-3,
New Delhi
…Petitioner &
(1) Managing Director,
Uttarakhand Power Corporation Ltd. (UPCL),
VCV Gabar Singh Urja Bhawan, Kanwali Road, Dehradun
(2) Executive Engineer,
Uttarakhand Power Corporation Ltd. (UPCL),
Electricity Distribution Division, SIDCUL, Haridwar
(3) Shri Suresh Kumar Srivastava,
S/o Late Sh. Jagdish Prasad Srivastava,
R/o A-19/601, Haridwar Greens, Haridwar
(4) President,
Haridwar Greens Residents’ Welfare Association (HGRWA),
Flat No.-101, Tower A-22, Haridwar Greens, Haridwar
…Respondents
14.02.2020
In the matter of:
Petition for seeking approval of the Commission for the investment on the
Implementation of Real Time Data Acquisition System (RTDAS) for
SAIFI/SAIDI measurement at 11 kV feeder level of 66 non SCADA towns of
UPCL under Integrated Power Development Scheme (IPDS) of Ministry of
Power, Govt. of India.
AND In the matter of:
Uttarakhand Power Corporation Ltd.,
Victoria Cross Vijeta Gabar Singh Urja Bhawan,
Kanwali Road, Dehradun
…Petitioner
04.02.2020
In the matter of:
Application for adjudication of dispute between Beta Infratech Private Limited and UPCL in respect
of termination of Power Purchase Agreement dated 01.03.2017 signed between Parties for
Procurement of 107 MW of power on long term basis from 225 MW (ISO) Gas Based Combined
Cycle Power Project in Village Mahuakhera Ganj, Kashipur, Distt. U.S. Nagar, Uttarakhand. In the matter of:
M/s Beta Infratech Private Limited … Petitioner AND In the matter of:
Uttarakhand Power Corporation Ltd. … Respondent
13.12.2019
In the matter of:
Petition under Section 86(1)(e) and 86(1)(f) in respect of 10.5 MW Sarju III Small Hydro Power Project of
Uttar Bharat Hydro Power Private Ltd.
In the matter of:
M/s Uttar Bharat Hydro Power Pvt. Ltd. ..... Petitioner AND In the matter of:
Uttarakhand Power Corporation Ltd. (UPCL) ..... Respondent No. 1
Power Transmission Corporation of Uttarakhand (PTCUL) ..... Respondent No. 2
15.11.2019
In the matter of:
Dispute between M/s Bhilangana Hydro Power Ltd and Power Transmission Corporation of
Uttarakhand Limited, relating to component ‘A' that is, regarding to transmission charges for
the use of intra-State transmission system for transmission of power from Bhilangana-III to
Uttarakhand Power Corporation Ltd. through Tata Power Trading Company Ltd.
In the matter of:
M/s Bhilangana Hydro Power Limited (BHPL) …………Petitioner
AND In the matter of:
Power Transmission Corporation of Uttarakhand Ltd. ……....Respondent
15.11.2019
In the matter of:
Petition under Section 86(1)(e) and 86(1)(f) in respect of 10.5 MW Sarju III Small Hydro Power Project of
Uttar Bharat Hydro Power Private Ltd.
In the matter of:
M/s Uttar Bharat Hydro Power Pvt. Ltd. ..... Petitioner
AND In the matter of:
Uttarakhand Power Corporation Ltd. (UPCL) ..... Respondent No. 1
Power Transmission Corporation of Uttarakhand (PTCUL) ..... Respondent No. 2
14.11.2019
In the matter of:
Representation/Petition under Section 67(4) Of The Electricity Act, 2003
AND In the matter of:
M/s Hero Reality Pvt. Ltd.,
264, Ground Floor, Okhla Industrial Estate, Phase-3,
New Delhi...................Petitioner
&
1) Managing Director,
Uttarakhand Power Corporation Ltd. (UPCL),
VCV Gabar Singh Urja Bhawan, Kanwali Road, Dehradun
(2) Executive Engineer,
Uttarakhand Power Corporation Ltd. (UPCL),
Electricity Distribution Division, SIDCUL, Haridwar
(3) The Ombudsman (Electricity),
80, Vasant Vihar, Phase-I, Dehradun
(4) Shri Suresh Kumar Srivastava,
S/o Late Sh. Jagdish Prasad Srivastava,
R/o A-19/601, Haridwar Greens, Haridwar
..........................Respondents
22.10.2019
In the matter of:
Petition to relax/waive or vary the provisions of UERC (Release of New LT Connections, Enhancement and Reduction of Loads) Regulations, 2007 and UERC (Release of New LT Connections, Enhancement and Reduction of Loads) Regulations, 2013 whereby the penalty was imposed in the matter of delay in release of new LT service connections for the period of F.Y. 2008-09 to F.Y. 2018-19 and upto Aug-2019.
In the matter of:
Uttarakhand Power Corporation Ltd.,
Victoria Cross Vijeta Gabar Singh Urja Bhawan,
Kanwali Road, Dehradun
…Petitioner
22.10.2019
In the matter of:
Petition for determination of Project Specific Tariff for Dunao Small Hydro Power Station (2 X 750
kW) of UJVN Ltd. under Section 62 and 86 of the Electricity Act, 2003 read with the relevant
Regulations, Orders and Guidelines of the Commission.
In the matter of:
UJVN Ltd. ................ Petitioner
AND In the Matter of:
Uttarakhand Power Corporation Ltd. … Respondent
22.10.2019
In the matter of:
Application for adjudication of dispute between Beta Infratech Private Limited and UPCL in
respect of termination of Power Purchase Agreement dated 01.03.2017 signed between Parties for
Procurement of 107 MW of power on long term basis from 225 MW (ISO) Gas Based Combined
Cycle Power Project in Village Mahuakhera Ganj, Kashipur, Distt. U.S. Nagar, Uttarakhand.
In the matter of:
M/s Beta Infratech Private Limited ............... Petitioner
AND In the Matter of:
Uttarakhand Power Corporation Ltd. ................ Respondent
09.09.2019
In the matter of:
Additional Surcharge levied by Uttarakhand Power Corporation Ltd. during the period 01st December 2014 to 31st of March 2017 on open access Power purchased by M/s Kashi Vishwanath Textile (P) Ltd.
In the matter of:
M/s Kashi Vishwanath Textile Mill (P) Ltd. … Petitioner
AND In the Matter of:
Managing Director, Uttarakhand Power Corporation Ltd. … Respondent
09.09.2019
In the matter of:
Petition to extend the Control Period of the benchmark capital cost and generic tariff as declared by the Commission vide its Order dated 07.06.2019, upto October, 2020 for upcoming Solar PV Power Plants (cumulative capacity of 52 MW).
In the matter of:
Uttarakhand Renewable Energy Development Agency (UREDA) … Petitioner
AND In the Matter of:
Uttarakhand Power Corporation Ltd. … Respondent
03.09.2019
In the matter of:
Petition for approval of Tariff rate revision from 70% CFA to Non CFA tariff rates for small solar plants, which already have 25 years PPA with UPCL, under the “Scheme for development of Grid Interactive Rooftop and Small Solar PV Power Projects-2016” for Residential/Institution/Social Sector, published on 29.09.2016, under Jawaharlal Nehru National Solar Mission.
In the matter of:
Akshay Urja Association …............................ Petitioner
AND In the Matter of:
Uttarakhand Power Corporation Ltd.
Uttarakhand Renewable Energy Development Agency (UREDA) …..................... Respondents
03.09.2019
In the matter of:
Petition for seeking carry forward of surplus of 139.00 MU (Non-Solar) Renewable Purchase Obligation of FY 2018-19 as per the provision of UERC (Compliance of Renewable Purchase Obligation) Regulation, 2010.
In the matter of:
Uttarakhand Power Corporation Ltd. .................... Petitioner
AND In the Matter of:
Uttarakhand Renewable Energy Development Agency … Respondent
03.09.2019
In the matter of:
Petition seeking Review of the order of the Commission dated April, 10, 2019 in petition no. 31 of 2017 seeking determination of project specific tariff for Tanga Hydro Power Project (5 MW) unit of M/s Himalaya Hydro Pvt. Ltd., under Section 94(1)(f) of the Electricity Act, 2003 and Regulation 54 of the UERC (Conduct of Business) Regulation 2014.
In the matter of:
M/s Himalaya Hydro Pvt. Ltd. ........................ Petitioner
AND In the Matter of:
Uttarakhand Power Corporation Ltd.......................... Respondent
15.07.2019
In the matter of:
Refund of Additional Surcharge paid to Uttarakhand Power Corporation Ltd. on power purchased through open access during 2013 to 2017 by Alps Industries Ltd.
In the matter of:
M/s Apls Industries Ltd. 57/2, Industrial Area, Sahibabad, Ghaziabad-201010 (Uttar Pradesh) …….…...Petitioner
AND In the Matter of:
1. Uttarakhand Power Corporation Ltd. Corporate Head Quarter, Victoria Cross Vijeyta Gabar Singh Urja Bhawan Kanwali Road, Balliwala Chowk, Dehradun.
2. Managing Director, Uttarakhand Power Corporation Ltd., Corporate Head Quarter, Victoria Cross Vijeyta Gabar Singh Urja Bhawan Kanwali Road, Balliwala Chowk, Dehradun.
3. Director (Finance) Uttarakhand Power Corporation Ltd., Corporate Head Quarter, Victoria Cross Vijeyta Gabar Singh Urja Bhawan Kanwali Road, Balliwala Chowk, Dehradun.
4. Director (Operation)Uttarakhand Power Corporation Ltd., Corporate Head Quarter, Victoria Cross Vijeyta Gabar Singh Urja Bhawan Kanwali Road, Balliwala Chowk, Dehradun.
5. The Chief Engineer (Distribution), Uttarakhand Power Corporation Ltd. Roshanabad, SIDCUL, Haridwar.
6. The Superintendent Engineer (Distribution), Uttarakhand Power Corporation Ltd. Roshanabad, SIDCUL, Haridwar.
7. The Executive Engineer, (Distribution) Uttarakhand Power Corporation Ltd. Roshanabad, SIDCUL, Haridwar.
……...Respondents
15.07.2019
In the matter of:
Dispute between M/s Bhilangana Hydro Power Ltd and Power Transmission Corporation of Uttarakhand Limited, relating to component A, that is, regarding to transmission charges for the use of intra-State transmission system for transmission of power from Bhilangana-III to Uttarakhand Power Corporation Ltd. through Tata Power Trading Company Ltd.
M/s Bhilangana Hydro Power Ltd ..… Petitioner
In the matter of:
Power Transmission Corporation of Uttarakhand Ltd. ..... Respondent
15.07.2019
In the matter of:
Petition under Section 86(1)(e) and 86(1)(f) in respect of 10.5 MW Sarju III Small Hydro Power Project of Uttar Bharat Hydro Power Private Ltd.
In the matter of:
M/s Uttar Bharat Hydro Power Pvt. Ltd. ..… Petitioner
AND In the Matter of:
Uttarakhand Power Corporation Ltd. ..... Respondent
15.07.2019
Daily order in the Matter of:
Gross Violation of the provisions of the Electricity Act, 2003, UERC (Release of New LT Connections, Enhancement and Reduction of Loads) Regulations, 2013 and UERC (The Electricity Supply Code) Regulations, 2007. In the Matter of:
Complaint of Sh. Parshuram S/o late Sh. Palturam, resident of Jagjeetpur, Post Office-Kankhal, Haridwar, Uttarakhand. … Petitioners
And In the Matter of: (1) Sh. Arvind Kumar,
(The then SDO-EDD Jwalapur Haridwar)
Executive Engineer-Raipur, 359/2, Dharampur, Dehradun
(2) Sh. Sandeep Chauhan,
(The then JE-EDD Jwalapur Haridwar)
O/o Executive Engineer-SIDCUL,
33/11 kV Sub-Station, Sector-8, SIDCUL, Haridwar … Respondent
10.07.2019
In the matter of:
APTEL’s Judgement dated 23.04.2019 in Appeal No. 287 of 2015. In the matter of:
M/s Swasti Power Ltd. … Petitioner AND In the Matter of:
Uttarakhand Power Corporation Ltd. … Respondent
12.06.2019
In the Matter of:
Petition seeking review of Impugned Order dated 20.06.2018 in Petition No. 04/2018 passed by the Commission under Section 94(1)(f) of the Electricity Act, 2003. In the Matter of:
M/s Amplus Solar Power Pvt. Ltd. M/s Asahi India Glass Ltd. … Petitioners
And In the Matter of: Uttarakhand Power Corporation Ltd. … Respondent
12.06.2019
In the Matter of:
1. Petition seeking implementation of Order passed on 10.04.2014 by the Commission for Vanala Small Hydro Power Electric Generating Station (15 MW) unit of M/s Him Urja Pvt. Ltd.
2. Petition seeking implementation of Order passed on 21.12.2012 by the Commission for Vanala Small Hydro Power Electric Generating Station (15 MW) unit of M/s Him Urja Pvt. Ltd.
3. Petition seeking implementation of Order passed on 17.03.2016 by the Commission for Rajwakti Small Hydro Power Project (4.4 MW) unit of M/s Him Urja Pvt. Ltd. In the Matter of: M/s Him Urja Pvt. Ltd. … Petitioner
And In the Matter of: Uttarakhand Power Corporation Ltd. … Respondent
30.05.2019
In the Matter of:
Refund of Additional Surcharge paid to Uttarakhand Power Corporation Ltd. on power purchased through open access during 2013 to 2017 by Alps Industries Ltd.
In the Matter of:
M/s Apls Industries Ltd., 57/2, Industrial Area, Sahibabad, Ghaziabad-201010 (Uttar Pradesh).…...Petitioner
02.04.2019
In the Matter of:
1. Petition seeking implementation of Order passed on 10.04.2014 by the Commission for Vanala Small Hydro Power Electric Generating Station (15 MW) unit of M/s Him Urja Pvt. Ltd.
2. Petition seeking implementation of Order passed on 21.12.2012 by the Commission for Vanala Small Hydro Power Electric Generating Station (15 MW) unit of M/s Him Urja Pvt. Ltd.
3. Petition seeking implementation of Order passed on 17.03.2016 by the Commission for Rajwakti Small Hydro Power Project (4.4 MW) unit of M/s Him Urja Pvt. Ltd.
In the Matter of: M/s Him Urja Pvt. Ltd. … Petitioner
And
Uttarakhand Power Corporation Ltd. … Respondent
02.04.2019
In the Matter of: Suo-moto proceeding initiated by the Commission in the matter of transfer of 66 kV Substation and Lines from UPCL to PTCUL.
And In the Matter of: Uttarakhand Power Corporation Limited (UPCL),
VCV Gabar Singh Urja Bhawan,
Kanwali Road, Dehradun
And
Power Transmission Corporation of Uttarakhand Limited (PTCUL), Vidyut Bhawan, Majra,
Dehradun ...Respondents
12.03.2019
In the Matter of:
Application seeking prior approval of the Commission on the Draft Power Purchase Agreement between Uttarakhand Power Corporation Limited and M/s Tata Power Trading Company Ltd. for procuring Non-Solar RE Energy on short term basis.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner And
M/s Tata Power Trading Company Ltd. … Respondent
12.03.2019
In the Matter of:
Dispute between M/s Bhilangana Hydro Power Limited and Uttarakhand Power Corporation Ltd., Regarding non-payment of Open Access Charges by UPCL for supply of non-solar renewable power by M/s Bhilangana Hydro Power Ltd. through Tata Power Trading Company Ltd. in FY 2016-17 and FY 2017-18.
In the Matter of:
M/s Bhilangana Hydro Power Limited (BHPL) …………Petitioner And
Uttarakhand Power Corporation Ltd. (UPCL) ……....Respondent
12.03.2019
In the Matter of:
Petition under Section 86(1)(e) and 86(1)(f) in respect of 10.5 MW Sarju III Small Hydro Power Project of Uttar Bharat Hydro Power Private Ltd.
In the Matter of:
M/s Uttar Bharat Hydro Power Pvt. Ltd. ..… Petitioner And
Uttarakhand Power Corporation Ltd. ..... Respondent
11.02.2019
In the Matter of:
Petition for review of the Commission’s Order dated 19.06.2018 read with letter No. 1144 dated 06.11.2018 on Suo moto proceeding regarding handing over of distribution business to UPCL.
And In the Matter of:
UJVN Limited , "UJJWAL", Maharani Bagh, GMS Road, Dehradun. …Petitioner And
Uttarakhand Power Corporation Limited (UPCL), Victoria Cross Vijeta Gabar Singh Urja Bhawan, Kanwali Road, Dehradun. ...Respondent
22.01.2019
In the Matter of:
Reconsider/Review petition filed under Regulation 54 of the UERC (Conduct of Business Regulations), 2014 for review of the Order dated 16.03.2017 passed by the Commission in the matter of determination of Project specific Tariff for 10.5 MW SHP on Sarju river at Kapkote, Bageshwar district, Uttarakhand u/s 62 & 86 (1)(b) and 86(1)(e) of the Electricity Act, 2003 read with Regulation 13 of UERC (Tariff and other Terms for Supply of Electricity from Non- Conventional and Renewable Energy Sources) Regulations, 2013. In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
And M/s Uttar Bharat Hydro Power Pvt. Ltd. … Respondent
22.01.2019
In the Matter of:
Reconsider/Review petition filed under Regulation 54 of the UERC (Conduct of Business Regulations), 2014 for review of the Order dated 21.08.2018 passed by the Commission in the matter of determination of Project specific Tariff for 12.6 MW SHP on Sarju river at Kapkote, Bageshwar district, Uttarakhand u/s 62 & 86 (1)(b) and 86(1)(e) of the Electricity Act, 2003 read with Regulation 13 of UERC (Tariff and other Terms for Supply of Electricity from Non- Conventional and Renewable Energy Sources) Regulations, 2013.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
And In the Matter of:
M/s Uttar Bharat Hydro Power Pvt. Ltd. … Respondent
22.01.2019
In the Matter of:
Petition to extend the control period of the benchmark capital cost & generic tariff as declared by the Commission vide its Order dated 06.09.2018, upto March 2020 for upcoming Solar PV Power Plants (Cumulative capacity of 200 MW).
In the matter of:
Uttarakhand Renewable Energy Development Agency (UREDA) … Petitioner And In the Matter of: Uttarakhand Power Corporation Ltd. … Respondent
28.12.2018
In the Matter of:
Petition under section 94(1) (f) of the Electricity Act, 2003 read with Regulation 54 of UERC (Conduct of Business) Regulations, 2014 regarding dispute between M/s Bhilangana Hydro Power Ltd. and PTCUL seeking review of the Order dated 22.11.2018 passed by the Commission in Petition No. 45 of 2018 in the matter of late Payment Surcharge against payment of Transmission Charges for the alleged dedicated Transmission Network. In the Matter of: M/s Bhilangana Hydro Power Limited. … Petitioner And In the Matter of: Power Transmission Corporation of Uttarakhand Ltd. … Respondent
18.12.2018
In the Matter of:
Petition seeking approval of one time registration fee to be collected from obligated entities for registration under Renewable Purchase Obligation Compliance System (RPOCS) in Uttarakhand. In the Matter of: M/s Uttarakhand Renewable Energy Development Agency … Petitioner
18.12.2018
In the Matter of:
Application seeking approval of the Commission on adjustment of tariff for Vanala Small Hydro Power Project (15 MW) unit of M/s Him Urja Pvt. Ltd. as per Section 61 and 62 of the Electricity Act, 2003 read with Regulation 14 & 15 of UERC (Tariff and Other Terms for Supply of Electricity from Renewable Energy Sources and non-fossil fuel based Co-generating Stations) Regulations, 2010, as amended from time to time seeking revision of tariff. In the Matter of: M/s Him Urja Pvt. Ltd. … Petitioner And In the Matter of: Uttarakhand Power Corporation Ltd. … Respondent
02.11.2018
In the Matter of:
Dispute between M/s Bhilangana Hydro Power Ltd. and PTCUL regarding Late Payment Surcharge against payment of Transmission Charges for the alleged dedicated transmission network.
And In the Matter of:
M/s Bhilangana Hydro Power Limited. …………Petitioner
And In the Matter of: Power Transmission Corporation of Uttarakhand Ltd. ……....Respondent
23.10.2018
In the Matter of:
Application seeking approval of Uttarakhand Electricity Regulatory Commission on the Draft Power Purchase Agreement for short term Power Purchase between Uttarakhand Power Corporation Ltd. and M/s Mittal Processors (P) Ltd., M/s PTC India Ltd., M/s Tata Power Trading Company Ltd., M/s Sembcorp Gayatri Power Ltd. & M/s GMR Energy Trading Ltd.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
And
M/s Mittal Processors (P) Ltd.
M/s PTC India Ltd.
M/s Tata Power Trading Company Ltd.
M/s Sembcorp Gayatri Power Ltd.
M/s GMR Energy Trading Ltd. … Respondents
14.08.2018
In the Matter of:
Petition under Section 94(1)(f) of the Electricity Act, 2003 read with Regulation 54 of the UERC (Conduct of Business) Regulation 2014 for review of the Order dated 17.05.2018 passed by the Commission in the Petition filed by M/s Him Urja Pvt. Ltd. seeking adjustment of tariff. In the Matter of:
M/s Him Urja Pvt. Ltd. … Petitioner
And In the Matter of:
Uttarakhand Power Corporation Ltd. … Respondent
07.08.2018
In the Matter of:
Petition seeking permission to set up Solar Power Plant of capacity 40 MW at Haripura Dam (27.34 MW) and Tumaria Dam (13.50 MW) in District Udham Singh Nagar, Uttarakhand on Net Metering basis for captive consumption by Department of Irrigation, Government of Uttarakhand through Superintending Engineer, Tubewell Circle, Dehradun. In the Matter of:
Superintending Engineer, Tubewell Circle, Irrigation Department, Govt. of Uttarakhand, Dehradun … Petitioner
And In the Matter of:
Uttarakhand Power Corporation Ltd., Uttarakhand Renewable Energy Development Agency … Respondents
07.08.2018
In the Matter of:
Application seeking approval for the investment on the project covering the construction of 01 No. 66/33 KV Substation & its 0.60 Km associated 66 kV line.
And In the Matter of:
Uttarakhand Power Corporation Limited (UPCL), Dehradun. …Petitioner
And
1) Managing Director, Power Transmission Corporation of Uttarakhand Ltd., Vidyut Bhawan, Majra, Dehradun.
2) Managing Director, UJVN Limited, "UJJWAL", Maharani Bagh, GMS Road, Dehradun. ...Respondents
31.07.2018
In the Matter of:
Application seeking prior approval of the Commission on the Draft Power Purchase Agreements for short term between Uttarakhand Power Corporation Limited and M/s Tata Power Trading Company Ltd., M/s PTC India Ltd. & M/s NTPC Vidyut Vyapar Nigam Ltd.
And In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
And In the Matter of:
M/s Tata Power Trading Company Ltd.
M/s PTC India Ltd.
M/s NTPC Vidyut Vyapar Nigam Ltd. … Respondents
24.07.2018
In the Matter of:
Application seeking review of the Tariff Order issued by the Commission on 21.03.2018 on the Annual Revenue Requirement and Tariff Petition of UPCL for FY 2018-19.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
24.07.2018
In the Matter of:
Petitions seeking approval of the Commission for advance banking of power to M/s PTC India Ltd., M/s Arunachal Pradesh Power Corporation Pvt. Ltd. & M/s Mittal Processors (P) Ltd. directly under a banking arrangement with the Uttarakhand Power Corporation Ltd.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
And In the Matter of:
M/s PTC India Ltd.
M/s Arunachal Pradesh Power Corporation Pvt. Ltd.
M/s Mittal Processors (P) Ltd. … Respondents
24.07.2018
In the Matter of:
Application seeking review of the Tariff Order issued by the Commission on 21.03.2018 on "True-up of FY 2016-17, Annual Performance Review for FY 2017-18 and Annual Fixed Charges for FY 2018-19 for UJVN Ltd."
And In the Matter of:
Managing Director, UJVN Ltd. ...Petitioner
17.07.2018
In the Matter of:
Suo-moto proceedings in the matter of Show Cause Notice issued to PTCUL under the provisions of Section 142 read with Section 149 of the Electricity Act, 2003, relating to construction of 132 kV line for M/s Gold Plus Glass Industries Ltd., Roorkee.
And In the Matter of:
1. Power Transmission Corporation of Uttarakhand Limited (PTCUL)
2. Uttarakhand Power Corporation Limited. (UPCL)
3. M/s Gold Plus Glass Industry Limited, Unit III (Roorkee) ………Respondents
17.07.2018
In the Matter of:
Suo-moto proceedings initiated by the Commission against non-compliance by UPCL of the provisions of UERC (Compliance of Renewable Purchase Obligation) Regulations, 2010 and Orders issued by the Commission from time to time.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Respondent
17.07.2018
In the Matter of:
Application seeking approval of the Commission on the Power Purchase Agreement between Uttarakhand Power Corp. Ltd. and M/s Aglar Power Ltd. for Lagrasu Plant.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
And In the Matter of:
M/s Aglar Power Ltd. … Respondent
17.07.2018
In the Matter of:
Application seeking approval of the Commission on the Power Purchase Agreement between Uttarakhand Power Corp. Ltd. and M/s Aglar Power Ltd. for Rayat Plant.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
And In the Matter of:
M/s Aglar Power Ltd. … Respondent
03.07.2018
In the Matter of:
Application seeking prior approval of the Commission on the Draft Power Purchase Agreement between Uttarakhand Power Corporation Limited and M/s Tata Power Trading Company Ltd. for procuring Non-Solar RE Energy on short term basis.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
And In the Matter of:
M/s Tata Power Trading Company Ltd. … Respondent
19.06.2018
In the Matter of:
Petition under Section 86(1)(f) of the Electricity Act, 2003 read with Article 23 of the PPAs, seeking payment of outstanding dues from Uttarakhand Power Corp. Ltd. for the common evacuation infrastructure constructed for 4x12.5 MW solar projects of ACME solar Holdings Pvt. Ltd., in terms of the power purchase agreements executed between the parties.
In the Matter of:
1. M/s ACME Solar Holdings Pvt. Ltd.
2. M/s Devishi Solar Power Pvt. Ltd.
3. M/s Eminent Solar Power Pvt. Ltd.
4. M/s Devishi Renewable Energy Pvt. Ltd.
5. M/s Sunworld Energy Pvt. Ltd. … Petitioners
And In the Matter of:
1. Uttarakhand Power Corporation Ltd. (UPCL)
2. Power Transmission Corporation of Uttarakhand Ltd. (PTCUL) … Respondents
19.06.2018
In the Matter of:
Suo moto proceeding initiated under Section 142 and Section 146 read with Section 149 of The Electricity Act, 2003 in the matter of violation of Section 12(b) of the Electricity Act, 2003 and non-compliance of the directions of the Commission issued vide its Tariff Order dated 29.03.2017.
And In the Matter of:
1. Managing Director, Uttarakhand Power Corporation Limited. (UPCL), VCV Gabar Singh Urja Bhawan, Kanwali Road, Dehradun.
2. Managing Director, UJVN Ltd, "UJJWAL", Maharani Bagh, GMS Road, Dehradun
3. Nodal Officer- Superientending Engineer, Uttarakhand Power Corporation Limited. (UPCL), Electricity Distribution Circle (Rural), Dehradun
4. Nodal Officer-Dy. General Manager, UJVN Ltd. Hydel Generation Circle, Dakpathar, Dehradun
... Respondents
25.05.2018
In the Matter of:
Application seeking prior approval of the Commission on the Draft Power Purchase Agreement between Uttarakhand Power Corporation Ltd. and M/s Tata Power Trading Company Ltd., M/s PTC India Ltd. & M/s Manikaran Power Ltd. for procuring Non-Solar RE Energy on short term basis. In the Matter of:
Uttarakhand Power Corporation Ltd. ... Petitioner
And In the Matter of:
M/s Tata Power Trading Company Ltd.
M/s PTC India Ltd.
M/s Manikaran Power Ltd. … Respondents
03.04.2018
In the Matter of:
Petition under Section 86(1)(f) of the Electricity Act, 2003 read with Article 23 of the PPAs, seeking payment of outstanding dues from Uttarakhand Power Corp. Ltd. for the common evacuation infrastructure constructed for 4x12.5 MW solar projects of ACME solar Holdings Pvt. Ltd., in terms of the power purchase agreements executed between the parties.
In the Matter of:
1. M/s ACME Solar Holdings Pvt. Ltd.
2. M/s Devishi Solar Power Pvt. Ltd.
3. M/s Eminent Solar Power Pvt. Ltd.
4. M/s Devishi Renewable Energy Pvt. Ltd.
5. M/s Sunworld Energy Pvt. Ltd. … Petitioners
And In the Matter of:
1. Uttarakhand Power Corporation Ltd. (UPCL)
2. Power Transmission Corporation of Uttarakhand Ltd. (PTCUL) … Respondents
03.04.2018
In the Matter of:
In the Matter of: Suo-moto proceedings initiated by the Commission on the representation of Shri R.S. Yadav, Vice President-HR & Admin, M/s India Glycols Ltd., A-1, Industrial Area Bazpur Road, Kashipur regarding Illegal demand of Cross Subsidy from Medium Term Open Access (MTOA) consumers by UPCL.
And In the Matter of:
1. M/s India Glycols Ltd., A-1, Industrial Area Bazpur Road, Kashipur.
2. M/s Hindustan National Glass Ltd. Malviya Nagar, Virbhadra Rishikesh.
3. M/s Ester India Ltd. Sohan Nagar, Charubeta, Khatima, U.S. Nagar.
4. Uttarakhand Power Corporation Limited (UPCL) ……Respondent
06.02.2018
In the Matter of:
Petition for approval of "Additional Capital Works amounting to 44.05 Crore of 4x76 MW Maneri Bhali-II HEP".
And In the Matter of: Uttarakhand Jal Vidyut Nigam Limited (UJVN Ltd.) "UJJWAL", Maharani Bagh, G.M.S. Road, Dehradun. ...Petitioner.
23.01.2018
In the Matter of:
Application seeking clarification with regard to the UERC (Tariff and Other Terms for Supply of Electricity from Renewable Energy Sources and non-fossil fuel based Co-generating Stations) Regulations, 2013 or, in the alternative, a specific order of relaxation or permission for establishment of a grid interactive roof-top solar plant with installed solar capacity of 3600 KW on captive consumption basis by the Applicant No. 1 and Applicant No. 2. In the Matter of:
M/s Amplus Solar Power Pvt. Ltd.
M/s Asahi India Glass Ltd. … Petitioners And In the Matter of:
Uttarakhand Power Corporation Ltd.
Uttarakhand Renewable Energy Development Agency … Respondents
23.01.2018
In the Matter of:
Application under Regulation 50 of the UERC (Tariff and Other Terms for Supply of Electricity from Renewable Energy Sources and non-fossil fuel based Co-generating Stations) Regulations, 2013. In the Matter of:
M/s Distributed Solar Power Association
M/s Amplus Solar Power Pvt. Ltd. … Petitioners And In the Matter of:
Uttarakhand Power Corporation Ltd.
Uttarakhand Renewable Energy Development Agency … Respondents
02.01.2018
In the Matter of:
Show cause Notice-cum-Notice for Personal Hearing issued to MD, UPCL in the matter of Non-compliance of sub-Regulation 14 of Regulation 5 & sub-Regulation 15 of Regulation 5 of UERC (Release of new LT Connections, Enhancement and Reduction of Loads) Regulations, 2013.
And In the Matter of: Managing Director, Uttarakhand Power Corporation of Ltd. (UPCL) ...Respondent
12.12.2017
In the Matter of:
Petition seeking approval of Power Purchase Agreement dated 05.02.2003 and Supplementary Power Purchase Agreement dated 07.12.2009 between Himalaya Hydro Pvt. Ltd. and Uttarakhand Power Corp. Ltd. for sale of power by Tanga Small Hydro Power Project (5 MW) of Himalaya Hydro Pvt. Ltd. located in Distt. Pithoragarh, Uttarakhand U/s 86(1)(b) of the Electricity Act, 2003 read with Regulation 7(3) of UERC (Tariff and Other Terms for Supply of Electricity from Renewable Energy Sources and non-fossil fuel based Co-generating Stations) Regulations, 2013 and Regulation 39 of UERC (Conduct of Business) Regulations, 2014.
In the Matter of:
M/s Himalaya Hydro Pvt. Ltd. … Petitioner
And In the Matter of:
Uttarakhand Power Corporation Ltd. … Respondent
28.11.2017
In the Matter of:
Clarification Petition under Regulation 59 and 61 r/w Regulation 54 of the UERC (Conduct of Business) Regulations, 2014 and Regulation, 2015 in the matter of Tariff Order dated 30.11.2016 passed by the Commission against Tariff Petition filed by M/s GBHPPL u/s 62 and 86(1)(a) of the Electricity Act, 2003 read with the relevant provisions of UERC (Terms & Conditions for Determination of Multi Year Tariff) Regulations, 2015 for determination of tariff for supply of power from their 70 MW Hydro Electric Power Project to UPCL.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
And In the Matter of:
M/s Greenko Budhil Hydro Power Pvt. Ltd. ... Respondent
08.11.2017
In the Matter of:
Additional Surcharge levied by Uttarakhand Power Corporation Ltd. during the period 01st December 2014 to 31stof March 2017 on open access Power Purchased.
In the Matter of: M/s Kashi Vishwanath Textile Mill (P) Ltd. .…...… Petitioner
And In the Matter of: Uttarakhand Power Corporation Ltd. (UPCL) …...... Respondent
13.10.2017
In the Matter of:
Additional Surcharge levied by Uttarakhand Power Corporation Ltd. during the period 01st December 2014 to 31st of March 2017 on open access Power purchased.
In the Matter of: M/s Kashi Vishwanath Textile Mill (P) Ltd. …...… Petitioner
And In the Matter of: Uttarakhand Power Corporation Ltd. (UPCL) ..... Respondent
06.10.2017
In the Matter of:
Additional Surcharge levied by Uttarakhand Power Corporation Ltd. during the period 01st December 2014 to 31st of March 2017 on open access Power purchased. In the Matter of: M/s Kashi Vishwanath Textile Mill (P) Ltd. …...… Petitioner
And In the Matter of:
Uttarakhand Power Corporation Ltd. (UPCL) ..... Respondent
15.09.2017
In the Matter of:
Application seeking approval of the Commission on the Draft Power Purchase Agreement between Uttarakhand Power Corporation Ltd. and M/s Avani Bio Energy Pvt. Ltd.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
And In the Matter of:
M/s Avani Bio Energy Pvt. Ltd. … Respondent
15.09.2017
In the Matter of:
Petition to extend the benchmark capital cost and generic tariff as declared by the Commission vide its Order dated 16.06.2016 (extended up to 31.09.2017 vide Order dated 16.05.2017), i.e. up to 31.01.2018 for Grid Interactive Rooftop & Small Solar Power Plants.
In the Matter of:
Uttarakhand Renewable Energy Development Agency (UREDA) … Petitioner
And In the Matter of:
Uttarakhand Power Corporation Ltd. … Respondent
28.08.2017
In the Matter of:
Application seeking approval of the Commission on the Bulk Power Purchase Agreement between UPCL and UJVN Ltd
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
In the Matter of:
UJVN Ltd. … Respondent
09.08.2017
In the Matter of:
Application seeking approval of the Commission on the Draft Power Purchase Agreement executed between Uttarakhand Power Corporation Ltd. and Uttarakhand Renewable Energy Development Agency.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
And In the Matter of:
Uttarakhand Renewable Energy Development Agency ... Respondent
28.07.2017
In the Matter of:
Investment approval for the investment on the project covering the construction of 01 No. 66/33 kV Substation & 0.60 Km 66 KV line and 02 No. 33/11 kV Substations & their associated 15.20 Km 33 kV line.
And In the Matter of: Uttarakhand Power Corporation Ltd., VCV Gabar Singh Urja Bhawan, Kanwali Road, Dehradun. …………Petitioner
28.07.2017
In the Matter of:
Non-compliance of the directions issued in the Tariff Order dated 29.03.2017 for FY 2017-18.
In the Matter of:
1. Sh. B.C.K. Mishra, Managing Director, UPCL.
2. Sh. M.A. Khan, Director (Finance), UPCL.
3. Sh. Atul Kumar Aggarwal, Director (Operation), UPCL. … Respondents
27.07.2017
In the Matter of:
Non-compliance of the directions issued in the Tariff Order dated 29.03.2017 for FY 2017-18.
In the Matter of:
1. Sh. R.S. Burfal, Chief Engineer (Haridwar), UPCL.
2. Sh. R.K. Rajora, Superintending Engineer (Haridwar), UPCL.
3. Sh. Amit Kumar, Superintending Engineer (Roorkee), UPCL.
4. Sh. V.S. Panwar, Executive Engineer (Haridwar-Urban), UPCL.
5. Sh. Y.S. Tomar, Executive Engineer (Haridwar-Rural), UPCL.
6. Sh. Devendra Kumar, Executive Engineer (Laksar), UPCL.
7. Sh. Anoop Kumar, Executive Engineer (Roorkee-Urban), UPCL. … Respondents
25.07.2017
In the Matter of:
Non-compliance of the directions issued in the Tariff Order dated 29.03.2017 for FY 2017-18.
In the Matter of:
1. Sh. J.M.S. Rauthan, Chief Engineer (Rudrapur), UPCL.
2. Sh. N.S. Tolia, Superintending Engineer (Rudrapur), UPCL.
3. Sh. Atul Singh Garbyal, Superintending Engineer (Pithoragarh), UPCL.
4. Sh. Pawan Singh, Executive Engineer (Pithoragarh), UPCL.
5. Sh. Rajesh Maurya, Executive Engineer (Champawat), UPCL.
6. Sh. Imtiaz Ahmad, Executive Engineer (Sitarganj), UPCL.
7. Sh. V.K. Pandey, Executive Engineer (Rudrapur), UPCL. … Respondents
In the Matter of:
Non-compliance of the directions issued in the Tariff Order dated 29.03.2017 for FY 2017-18. In the Matter of:
1. Sh. H.K. Gururani, Chief Engineer (Kumaon), UPCL.
2. Sh. Tarun Kumar, Superintending Engineer (Ranikhet), UPCL.
3. Sh. S.C. Tripathi, Superintending Engineer (Haldwani), UPCL.
4. Sh. M.R. Arya, Superintending Engineer (Kashipur), UPCL.
5. Sh. Umakant Chaturvedi, Executive Engineer (Ranikhet), UPCL.
6. Sh. Bhaskar Pandey, Executive Engineer (Bageshwar), UPCL.
7. Sh. Nitin Singh Garkhal, Executive Engineer (Haldwani), UPCL.
8. Sh. Amit Anand, Executive Engineer (Ramnagar), UPCL.
9. Sh. Vivek Kandpal, Executive Engineer (Kashipur), UPCL.
10. Sh. Ajit Kumar Yadav, Executive Engineer (Bazpur), UPCL. … Respondents
11.07.2017
In the Matter of:
Petition seeking determination of project specific tariff for Tanga Small Hydro Power Project (5 MW) of Himalaya Hydro Pvt. Ltd. located in Pithoragarh, Uttarakhand, U/s 62, 86(1)(b) & 86(1)(e) of the Electricity Act, 2003 read with Regulation 10(2) and 13 of UERC (Tariff and Other Terms for Supply of Electricity from Renewable Energy Sources and non-fossil fuel based Co-generating Stations) Regulations, 2013.
In the Matter of:
M/s Himalaya Hydro Pvt. Ltd. … Petitioner
And In the Matter of:
Uttarakhand Power Corporation Ltd. ... Respondent
30.05.2017
In the Matter of:
Petition for seeking carry forward of Renewable Purchase Obligation of FY 2016-17 amounting to 787.68 MU (Non-Solar) and 161.32 MU (Solar) as per the provisions of UERC (Compliance of Renewable Purchase Obligation) Regulations, 2010.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
And In the Matter of:
Uttarakhand Renewable Energy Development Agency (UREDA) … Respondent
17.05.2017
In the Matter of:
Petition filed under Regulation 59 and 39 of the UERC (Conduct of Business) Regulations, 2014 and Regulation 55A, 103, 104 & 105 of MYT Regulations, 2015.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
And In the Matter of:
M/s Beta Infratech Pvt. Ltd.
M/s Gama Infraprop (P) Ltd.
M/s Sravanthi Energy Pvt. Ltd. … Respondents
16.05.2017
In the Matter of:
Investment approval on the project for implementing Integrated Automatic Meter Reading System on 12000 nos. Consumers to be executed on turnkey basis.
In the Matter of: Uttarakhand Power Corporation Ltd., VCV Gabar Singh Urja Bhawan, Kanwali Road, Dehradun. …………Petitioner
16.05.2017
In the Matter of:
Misc. Application filed against the shifting of High Tension Line (33 KV) in Prakash Vihar, Haridwar Road, Dehradun under section 67(4) of The Electricity Act, 2003.
And In the Matter of: Smt. Anita Gupta & Ors. …….............Petitioners Vs
1. Secretary (Energy), GoU, Secretariat, Dehradun
2. Managing Director, UPCL, Dehradun
3. Senior Superintendent of Police, Dehradun ……….Respondents
16.05.2017
In the Matter of:
Application seeking approval of the Fuel Charge Adjustment (FCA) to be charged from the consumers for the period from 01.04.2017 to 30.06.2017. In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
03.05.2017
In the Matter of:
Petition for determination for Project Specific Tariff in respect of 12.6 MW Sarju-II Small Hydro Power Project on Sarju River in Kapkote, Distt. Bageshwar, Uttarakhand.
In the Matter of:
M/s Uttar Bharat Hydro Power Pvt. Ltd. … Petitioner
And In the Matter of:
Uttarakhand Power Corporation Ltd. … Respondent
02.05.2017
In the Matter of:
Application seeking approval of the Commission on the Draft Power Purchase Agreement between UPCL & UJVN Ltd.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
And In the Matter of:
UJVN Ltd. … Respondent
15.03.2017
In the Matter of:
Application seeking approval of the Commission on the Power Purchase Agreement between Uttarakhand Power Corporation Ltd. and M/s Melkhet Power Pvt. Ltd.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
And In the Matter of:
M/s Melkhet Power Pvt. Ltd.
Power Transmission Corporation of Uttarakhand Ltd. … Respondents
15.03.2017
In the Matter of:
Petition for Review of Order dated 30.11.2016 passed by the Commission on "Petition for re-determination of Generic Tariff for Mohammadpur Small Hydro Generating Station (3x3.1 MW)" and "Petition for re-determination of Generic Tariff for Pathri Small Hydro Generating Station (3x6.8 MW)" of UJVN Ltd. under Section 62, 86 and 94(1)(f) of the Electricity Act, 2003 read with the relevant Regulations, Orders and Guidelines of the Commission.
In the Matter of:
UJVN Ltd. … Petitioner
And In the Matter of:
Uttarakhand Power Corporation Ltd. … Respondent
15.03.2017
In the Matter of:
Petition seeking adjustment of tariff for Vanala Small Hydro Power Project (15 MW) unit of M/s Him Urja Pvt. Ltd. as per Section 61 and 62 of the Electricity Act, 2003 read with Regulation 14 & 15 of UERC (Tariff and Other Terms for supply of Electricity from Renewable Energy Sources and Non fossil fuel based Co- generating Stations) Regulations, 2010, as amended from time to time seeking revision of tariff.
In the Matter of:
M/s Him Urja Pvt. Ltd. … Petitioner
And In the Matter of:
Uttarakhand Power Corporation Ltd. … Respondent
10.03.2017
In the Matter of: Investments approval for improvement of Bill Collection Facilities of UPCL in lieu of the Order dated 01.09.2005 passed by the Commission.
In the Matter of: Uttarakhand Power Corporation Ltd., VCV Gabar Singh Urja Bhawan, Kanwali Road, Dehradun. …………Petitioner
10.03.2017
In the Matter of:
Petition to relax or vary the provisions of UERC (Release of New LT Connections, Enhancement and Reduction of Loads) Regulations, 2007 and UERC (Release of New LT Connections, Enhancement and Reduction of Loads) Regulations, 2013 whereby the penalty was imposed in the matter of delay in release of new LT service connections for the period of FY 2008-09 to FY 2015-16. And In the Matter of: Uttarakhand Power Corporation Ltd. (UPCL) …Petitioner
24.01.2017
In the Matter of:
Application seeking approval of the Commission on the Power Purchase Agreement between Uttarakhand Power Corporation Ltd. and M/s K. Ramachandra Rao Transmission & Projects Pvt. Ltd.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner And In the Matter of:
M/s K. Ramachandra Rao Transmission & Projects Pvt. Ltd. ... Respondent
09.01.2017
In the Matter of:
Approval of Capital Investments under Para 11 of the Transmission and Bulk Supply Licence for Investment approval for Shifting of 132 kV lines in Dev Sanskriti Vishvavidyalaya Campus for Shri Ved Mata Gayatri Trust Shantikunj Haridwar.
And In the Matter of:
Power Transmission Corporation of Uttarakhand Ltd., ‘Vidyut Bhawan’, Majra, Dehradun. … Petitioner
& In the Matter of: Uttarakhand Power Corporation Ltd., VCV Gabar Sing Urja Bhawan, Kanwali Road, Dehradun. … Respondent No. 1
Shri Ved Mata Gayatri Trust, Gayatri Teerth, Shantikunj, Haridwar-249411 … Respondent No. 2
09.01.2017
In the Matter of:
Petition for approval of Business Plan of M/s Sravanthi Energy Pvt. Ltd. for the Control Period starting from FY 2016-17 to FY 2018-19 for supply of 214 MW of power to UPCL from 428 MW Gas based Kashipur Combined Cycle Power Plant of M/s Sravanthi Energy Pvt. Ltd. at Village Khaikhera, Kashipur, District Udhamsingh Nagar.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
And In the Matter of:
M/s Sravanthi Energy Pvt. Ltd. ... Respondent
09.01.2017
In the Matter of:
Petition under Clause No. 59 of UERC (Conduct of Business) Regulations, 2014 and Clause No. 103 of UERC (Terms & Conditions for Determination of Multi Year Tariff) Regulations, 2015 for amendment of Clause No. 9 "Billing and Payment", Clause No. 1.1.32 "Due Date" and Clause No. 9.4 "Payment Security Mechanism" of Power Purchase Agreement for procurement of 107 MW of Power on Long Term Basis between 225 MW Gas based Kashipur Combined Cycle Power Plant of Gama Infraprop Pvt. Ltd. at Mahuakhedaganj, Kashipur, Distt. Udhamsingh Nagar, Uttarakhand and Uttarakhand Power Corp. Ltd. (UPCL).
In the Matter of:
M/s Gama Infraprop (P) Ltd. … Petitioner
And In the Matter of:
Uttarakhand Power Corporation Ltd. ... Respondent
09.01.2017
In the Matter of:
Petition filed under Regulation 9, 20, 58, 59, 61 and 62 of the UERC (Conduct of Business) Regulations, 2014 and Regulation 49 & 50 of UERC RE Regulations, 2013 for adjudication of dispute and other matter between M/s Vivan Solar Pvt. Ltd. and UPCL.
And In the Matter of:
Petition filed under Regulation 9, 20, 58, 59, 61 and 62 of the UERC (Conduct of Business) Regulations, 2014 and Regulation 49 & 50 of UERC RE Regulations, 2013 for adjudication of dispute and other matter between M/s Purshotam Industries Ltd. and UPCL.
And In the Matter of:
Petition filed under Regulation 9, 20, 58, 59, 61 and 62 of the UERC (Conduct of Business) Regulations, 2014 and Regulation 49 & 50 of UERC RE Regulations, 2013 for adjudication of dispute and other matter between M/s Purshotam Ispat and UPCL.
And In the Matter of:
Petition filed under Regulation 9, 20, 58, 59, 61 and 62 of the UERC (Conduct of Business) Regulations, 2014 and Regulation 49 & 50 of UERC RE Regulations, 2013 for adjudication of dispute and other matter between M/s Eastman International and UPCL.
In the Matter of:
1. M/s Vivan Solar Pvt. Ltd.
2. M/s Purshotam Industries Ltd.
3. M/s Purshotam Ispat
4. M/s Eastman International … Petitioners
And In the Matter of:
Uttarakhand Power Corporation Ltd. ... Respondent
27.12.2016
In the Matter of:
Investment approval for Construction of Colony at 132 kV Substation Majra Campus, Dehradun.
In the Matter of: Power Transmission Corporation of Uttarakhand Ltd., Vidyut Bhawan, Majra, Dehradun. …………Petitioner
27.12.2016
In the Matter of: Investment approval for procurement and stringing of 132 kV Roorkee-Laksar line by replacing existing wolf/panther conductor with HTLS Conductor.
In the Matter of: Power Transmission Corporation of Uttarakhand Ltd., Vidyut Bhawan, Majra, Dehradun. …………Petitioner
27.12.2016
In the Matter of:
Investment approval for procurement and stringing of 132 kV Roorkee-Manglore line by replacing existing wolf/panther conductor with HTLS Conductor.
In the Matter of: Power Transmission Corporation of Uttarakhand Ltd., Vidyut Bhawan, Majra, Dehradun.
22.12.2016
In the Matter of:
Review Petition filed under Regulation 54 of the UERC (Conduct of Business) Regulations, 2014 for review of the Order dated 28th Oct., 2016 passed by the Commission in the matter of Adjudication of dispute under Section 86(1)(f) between Uttar Bharat Hydro Power (P) Ltd. & Uttarakhand Power Corporation Ltd. in respect of 10.5 MW Sarju-III Small Hydro Power Project.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
And In the Matter of:
M/s Uttar Bharat Hydro Power (P) Ltd. … Respondent
09.12.2016
In the Matter of:
Application seeking approval of the Commission on the Power Purchase Agreement between Uttarakhand Power Corporation Ltd. and M/s Uttar Bharat Hydro Power Pvt. Ltd.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
And In the Matter of:
M/s Uttar Bharat Hydro Power Pvt. Ltd. ... Respondent
09.12.2016
In the Matter of:
Application seeking approval of the Commission on the Power Purchase Agreement between Uttarakhand Power Corp. Ltd. and Khutani Hydro Power Project.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
AND
In the Matter of:
M/s Khutani Power Company Pvt. Ltd. ... Respondent
15.11.2016
In the Matter of:
Application seeking approval of the Commission on the Draft Power Purchase Agreement between Uttarakhand Power Corp. Ltd. and M/s Beta Infratech Pvt. Ltd.
In the Matter of: Uttarakhand Power Corporation Ltd. … Petitioner
AND
In the Matter of: M/s Beta Infratech Pvt. Ltd. … Respondent
15.11.2016
In the Matter of:
In the matter of: Waiver and refund of penalty imposed by the Commission vide its Order dated 01.09.2005. &
Show Cause Notice issued by the Commission vide its letter dated 18.04.2016.
AND
In the Matter of: Uttarakhand Power Corporation Ltd. (UPCL) …... Petitioner
04.11.2016
In the Matter of:
Petition to determine the project specific Tariff of Chamoli Extension Mini Hydro Power Project of Capacity of 3 MW on cost plus approach.
In the Matter of: Uttarakhand Renewable Energy Development Agency … Petitioner AND In the Matter of: Uttarakhand Power Corporation Ltd. ... Respondent
18.10.2016
In the Matter of:
Approval of Capital Investments under Para 11 of the Transmission and Bulk Supply Licence for Investment approval for Augmentation of Transformation capacity from 2x40 MVA (132/33 KV) to 3x40 MVA (132/33 KV) by commissioning of 01 No. additional 132/33 KV 40 MVA T/F, HV & LV bay & oil pit for NIFPES & construction of 03 Nos. new 33 KV feeder Bays at 132 KV S/s Jashodharpur, Kotdwar (Pauri Garhwal).
In the Matter of: Power Transmission Corporation of Uttarakhand Ltd., Vidyut Bhawan, Majra, Dehradun. …………Petitioner
18.10.2016
In the Matter of:
In the Matter of: Approval of Capital Investments under Para 11 of the Transmission and Bulk Supply Licence for Investment approval for Augmentation of 132 KV Substation Bindal from 2x40 MVA (132/33 kV) to 3x40 MVA (132/33 kV) by procurement, Installation & Commissioning of 132/33KV, 40 MVA Transformer at 132 kV Substation Bindal, Dehradun.
In the Matter of:
Power Transmission Corporation of Uttarakhand Ltd., Vidyut Bhawan, Majra, Dehradun. …………Petitioner
18.10.2016
In the Matter of:
Approval of Capital Investments under Para 11 of the Transmission and Bulk Supply Licence for Investment approval for Shifting of 132 kV lines in Dev Sanskriti Vishvavidyalaya Campus for Shri Ved Mata Gayatri Trust Shantikunj Haridwar.
In the Matter of: Power Transmission Corporation of Uttarakhand Ltd., Vidyut Bhawan, Majra, Dehradun. …………Petitioner
05.10.2016
In the Matter of:
Petition seeking determination of provisional tariff in anticipation of completion of Tanga Small Hydro Power Project (5 MW) of Himalaya Hydro Pvt. Ltd., as per Regulation 13, Sub-Clause (2) and Regulation 10, Sub-Clause (2) (option for fixation of "Project Specific Tariff") of UERC (Tariff and Other Terms for Supply of Electricity from non-conventional and Renewable Energy Sources) Regulations, 2013.
In the Matter of:
M/s Himalaya Hydro Pvt. Ltd. … Petitioner
AND
Uttarakhand Power Corporation Ltd. ... Respondent
20.09.2016
In the Matter of:
Investment Approval for Construction of Separate Building for SLDC at 132 KV Substation, Majra Campus, Dehradun.
In the Matter of:
Power Transmission Corporation of Uttarakhand Ltd., Vidyut Bhawan, Majra, Dehradun.
…………Petitioner
07.09.2016
In the Matter of:
Petition seeking approval of Business Plan for the Control Period starting from FY 2016-17 to FY 2018-19 for 214 MW Gas based Kashipur Combined Cycle Power Plant of Gama Infraprop Private Ltd. at Mahukhedaganj, Kashipur, District Udhamsingh Nagar, Uttarakhand.
In the Matter of:
M/s Gama Infraprop (P) Ltd. …Petitioner
AND
In the Matter of:
Uttarakhand Power Corporation Ltd. ...Respondent
06.09.2016
In the Matter of:
Show Cause Notice–cum–Notice for Personal Hearing:-
1. Offence of misleading the electricity consumers of the State by publishing wrongful interpretation of the provisions of the UERC (Release of new LT Connections, Enhancement and Reductions of Loads) Regulations, 2013.
2. Contravention of Regulation 7 of UERC (Release of new LT Connections, Enhancement and Reductions of Loads) Regulations, 2013.
In the Matter of:
1. S.S Yadav,
Managing Director, UPCL, Dehradun.
2. A.K Agarwal,
Director (Operations), UPCL, Dehradun.
3. H.K Gururani,
Chief Engineer (Distribution), UPCL, Kumaon Zone, Haldwani.
4. Navin Mishra,
Executive Engineer, UPCL, Haldwani (Urban)
5. Nitin Singh Garkhal,
Executive Engineer, UPCL, Ramnagar ....Respondents
06.09.2016
In the Matter of:
Approval of Capital Investments under Para 11 of the Transmission and Bulk Supply Licence for:
1. Augmentation of 220 kV S/s Roorkee by adding of 220/33 kV, 2x50 MVA Transformers.
2. Increasing Capacity of 132/33 kV S/s Jaspur from 2x40 MVA to 3x40 MVA including
construction of associated 01 No. 132 KV bay and 01 No. 33 kV bay and bisection of 132 kV
& 33 kV Bus.
3. Stringing of Second Circuit of 132 kV D/C Satpuli-Kotdwar Transmission Line.
4. Augmentation of 132/33 kV transformer capacity at 220 kV substation Haldwani from 2x40
MVA to 3x40 MVA including construction of associated 01 no. 132 kV bay and 01 no. 33 kV
bay and extension & bisection of 132 kV & 33 kV bus.
5. Augmentation of 132/33 kV transformer capacity at 132 kV substation Pithoragarh from
2x20 MVA + 2x3x5 MVA to 1x20 MVA + 1x40 MVA + 2x3x5 MVA. In the Matter of:
Power Transmission Corporation of Uttarakhand Ltd., Vidyut Bhawan, Majra, Dehradun.……Petitioner
06.09.2016
In the Matter of:
Petition filed under Regulation 37(1)of the UERC (Conduct of Business Regulations),
2014, clause 3.2 and 14A of the Transmission license read with section 18 of the Electricity
Act and other relevant provisions of the Electricity Act, 2003 for amending the terms
and condition of the Transmission License of Power Transmission Corporation of
Uttarakhand Ltd. In the Matter of:
Power Transmission Corporation of Uttarakhand Ltd.,
Vidyut Bhawan, Majra, Dehradun………Petitioner
09.08.2016
In the Matter of:
Petition on Relaxation in RE Regulations, 2013 in respect to Sarju-II & Sarju-III SHPs of M/s UBHP Ltd. for restriction of any claim under deemed generation on account of the restraint in evacuation system caused due to allowance of evacuation of power from Sarju-II SHP, till the under constructed 33 kV line between Bageshwar and Kapkote on panther conductor is completed. In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
And In the Matter of:
M/s Uttar Bharat Hydro Power (P) Ltd. … Respondent
09.08.2016
In the Matter of:
Suo-moto proceedings initiated by the Commission in accordance with the Agreement dated 21.11.1972 between Govt. of Himachal Pradesh and Govt. of Uttar Pradesh.
In the Matter of:
Uttarakhand Power Corporation Ltd.
UJVN Ltd. … Respondents
In the Matter of:
Application seeking approval of the Commission on the Model Power Purchase Agreement between Uttarakhand Power Corp. Ltd. & Grid Interactive Rooftop and Small Solar PV Power Plant.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
21.06.2016
In the Matter of:
Review petition filed under Regulation 54 of the UERC (Conduct of Business) Regulations, 2014 for review of the Order dated 5th April, 2016 passed by the Commission in the matter of Petition for approval of Business Plan and determination of Multi Year Tariff Petition for Second Control Period 2016-17 to 2018-19, True up of FY 2014-15 and Annual Performance Review for FY 2015-16 of Power Transmission Corporation of Uttarakhand Ltd.
In the Matter of:
Power Transmission Corporation of Uttarakhand Ltd. … Petitioner
And In the Matter of:
Uttarakhand Power Corporation Ltd. ... Respondent
21.06.2016
In the Matter of:
Petition seeking adjustment of tariff of Vanala Small Hydro Project (15 MW) of M/s Him Urja Pvt. Ltd. as per Section 61 and 62 of the Electricity Act, 2003 read with Regulation 16(3) & 25 of UERC (Tariff and Other Terms for supply of Electricity from RE Sources and Non-fossil fuel based Co-generating Station) Regulations, 2010, as amended from time to time and Regulation 3 & 4 (4) of the UERC (T&C for truing up of Tariff) Regulations, 2008.
In the Matter of:
M/s Him Urja Pvt. Ltd. … Petitioner
21.06.2016
In the Matter of:
Application seeking prior approval of the Commission on the Draft Power Purchase Agreement for short term between Uttarakhand Power Corp. Ltd. and M/s Tata Power Trading Company Ltd. (TPTCL), M/s PTC India Ltd. & M/s Adani Enterprises Ltd.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
21.06.2016
In the Matter of:
Application seeking approval of the Commission on the Draft Power Purchase Agreement between Uttarakhand Power Corporation Limited and M/s Sravanthi Energy Pvt. Ltd.
In the Matter of:
M/s Sravanthi Energy Pvt. Ltd. … Petitioner
AND
In the Matter of:
Uttarakhand Power Corporation Ltd. ... Respondent
21.06.2016
In the Matter of:
Application seeking approval of the Commission on the Draft Power Purchase Agreement between Uttarakhand Power Corporation Ltd. and Sh. Rakesh Kumar.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
AND
In the Matter of:
Sh. Rakesh Kumar ... Respondent
21.06.2016
In the Matter of:
Application seeking approval of the Commission on the Draft Power Purchase Agreement between Uttarakhand Power Corporation Limited and M/s Dans Energy Pvt. Ltd.
In the Matter of:
Uttarakhand Power Corporation Limited … Petitioner
AND
In the Matter of:
M/s Dans Energy Pvt. Ltd. ... Respondent
07.06.2016
In the Matter of:
Investment approval for Procurement, Erection & Commissioning of 01 No. 40 MVA 132/33 kV Transformer complete with 132 kV & 33 kV Bay for increasing capacity of 132 kV Substation Laksar.
AND
In the Matter of:
Power Transmission Corporation of Uttarakhand Limited (PTCUL) Vidyut Bhawan, Near ISBT Crossing, Saharanpur Road, Majra, Dehradun ........Petitioner
07.06.2016
In the Matter of:
In the matter of: Petition for prior approval of "Capital Investment for Renovation & Modernization" of Dhakrani (3x11.25 MW) HEP of UJVN Ltd.
AND
In the Matter of: UJVN Ltd. "UJJWAL", Maharani Bhagh, GMS Road, Dehradun …Petitioner
07.06.2016
In the Matter of:
In the matter of: Investment Approval of Revised DPR for Construction of 132 kV S/C Over head line on Double Circuit Tower from 220 kV S/s SIDCUL Haridwar to 132 kV S/s Jwalapur Haridwar.
AND
In the Matter of:
Power Transmission Corporation of Uttarakhand Limited (PTCUL) Vidyut Bhawan, Near ISBT Crossing, Saharanpur Road, Majra, Dehradun ........Petitioner
07.06.2016
In the Matter of:
In the matter of: Investment Approval for Balance work of "Diversion of 220 kV Rishikesh-Dharasu and Chamba-Dharasu line in THDC submerged area."
AND
In the Matter of: Power Transmission Corporation of Uttarakhand Limited (PTCUL) Vidyut Bhawan, Near ISBT Crossing, Saharanpur Road, Majra, Dehradun ........Petitioner
07.06.2016
In the Matter of:
Application seeking approval of Hon’ble UERC on the Draft Power Purchase Agreement between Uttarakhand Power Corporation Ltd. and M/s Tata Power Trading Co. Ltd. & M/s Shree Cement Ltd.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
AND
In the Matter of:
M/s Tata Power Trading Co. Ltd. ... Respondent No. 1
M/s Shree Cement Ltd. ... Respondent No. 2
07.06.2016
In the Matter of:
Application seeking approval of Hon’ble UERC on the Draft Power Purchase Agreement between Uttarakhand Power Corporation Ltd. & Grid Interactive Rooftop & Small Solar PV Plant under Suryodaya Swarozgar Yozna.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
AND
In the Matter of:
Uttarakhand Renewable Energy Development Agency ... Respondent
07.06.2016
In the Matter of:
Application seeking approval of Hon’ble UERC on the Draft Power Purchase Agreement between Uttarakhand Power Corporation Ltd. and M/s Avani Bio Energy Pvt. Ltd. (33 kV Grid Sub-station at Kunatta, Pithoragarh, Uttarakhand).
AND
Application seeking approval of Hon’ble UERC on the Draft Power Purchase Agreement between Uttarakhand Power Corporation Ltd. and M/s Avani Bio Energy Pvt. Ltd. (33 kV Grid Sub-station at Raiagar, Tripuradevi, Pithoragarh, Uttarakhand).
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
AND
In the Matter of:
M/s Avani Bio Energy Pvt. Ltd. ... Respondent
07.06.2016
In the Matter of:
Petition for seeking carry forward of Renewable Purchase Obligation for FY 2015-16 amounting to 699.6 MU (Non-Solar) and 8.1 MU (Solar) as per the provisions of UERC (Compliance of Renewable Purchase Obligation) Regulations, 2010.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
AND
In the Matter of:
Uttarakhand Renewable Energy Development Agency ... Respondent
07.06.2016
In the Matter of:
Application seeking approval of Hon’ble UERC on the Draft Power Purchase Agreement between Uttarakhand Power Corporation Ltd. and UJVN Ltd. (4.5 MW Canal Bank Grid connected Solar PV Plant).
&
Application seeking approval of Hon’ble UERC on the Draft Power Purchase Agreement between Uttarakhand Power Corporation Ltd. and UJVN Ltd. (1 MW Canal Top Grid connected Solar PV Plant).
&
Application seeking approval of Hon’ble UERC on the Draft Power Purchase Agreement between Uttarakhand Power Corporation Ltd. and UJVN Ltd. (7.5 MW Canal Bank Grid connected Solar PV Plant).
&
Application seeking approval of Hon’ble UERC on the Draft Power Purchase Agreement between Uttarakhand Power Corporation Ltd. and UJVN Ltd. (7 MW Canal Bank Grid connected Solar PV Plant).
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
AND
In the Matter of:
UJVN Ltd. ... Respondent
07.06.2016
In the Matter of:
Petition under Sections 62 and 86(1)(a) of the Electricity Act, 2003 read with the relevant provisions of UERC (Terms & Conditions for Determination of Tariff) Regulations, 2011, UERC (Terms & Conditions for Determination of Multi Year Tariff) Regulations, 2015 for determination of tariff for supply of power from the Petitioner’s 70 MW Hydro - electric power project to UPCL & approval of Business Plan from FY 2016-17 to FY 2018-19.
In the Matter of:
M/s Greenko Budhil Hydro Power Pvt. Ltd. … Petitioner
AND
In the Matter of:
Uttarakhand Power Corporation Ltd. … Respondent
19.04.2016
In the Matter of:
Petition to approve the ‘Date of Commercial Operation’ (CoD) of the damaged/non-functional 8 Small Hydro Power Plants (SHPs) on the date when these SHPs will start operating after renovation & modernization works.
In the Matter of:
Uttarakhand Renewable Energy Development Agency . … Petitioner
AND
In the Matter of:
Uttarakhand Power Corporation Ltd. ... Respondent
19.04.2016
In the Matter of:
Adjudication of dispute under Section 86(1)(f) between Uttar Bharat Hydro Power Pvt. Ltd. and Uttarakhand Power Corporation Ltd. in respect of 10.5 MW Sarju III Small Hydro Power Project.
In the Matter of:
M/s Uttar Bharat Hydro Power Pvt. Ltd. . … Petitioner
AND
In the Matter of:
Uttarakhand Power Corporation Ltd. ... Respondent
19.04.2016
In the Matter of:
Adjudication of dispute under 86(1)(f) between Uttar Bharat Hydro Power Private Limited and Uttarakhand Power Corporation Limited in respect of 12.6 MW Sarju II Hydro Power Project.
In the Matter of:
M/s Uttar Bharat Hydro Power Pvt. Ltd. . … Petitioner
AND
In the Matter of:
Uttarakhand Power Corporation Ltd. ... Respondent
19.04.2016
In the Matter of:
Construction of 132 kV GIS Substation Araghar and LILO of 132 kV Majra-Laltappar at 132 kV S/s Araghar line through laying of 132 kV Cable.
In the Matter of:
Power Transmission Corporation of Uttarakhand Ltd. . … Petitioner
16.03.2016
In the Matter of:
Petition seeking the payment for Deemed Generation of 5 MW Debal Small Hydro Project for the years 2012-13, 2013-14 & 2014-15.
In the Matter of:
M/s Chamoli Hydro Power Pvt. Ltd. … Petitioner
AND
In the Matter of:
Uttarakhand Power Corporation Ltd. ... Respondent
26.02.2016
In the Matter of:
Petition seeking approval of the Business Plan U/s 62 & 86 (1)(a) of the Electricity Act, 2003 read with the Regulation 8 of UERC (Terms & Conditions for Determination of Multi Year Tariff) Regulations, 2015 and as per Commission’s order dated 20.11.2015 & Determination of tariff for supply of power from the Petitioner’s 70 MW Hydro–electric power project to UPCL.
AND
In the Matter of:
M/s Greenko Budhil Hydro Power Pvt. Ltd. ...Petitioner
AND
In the Matter of:
Uttarakhand Power Corporation Ltd. ... Respondent
26.02.2016
In the Matter of:
Petition to extent the benchmark capital cost and generic tariff as declared by UERC vide its order dated 23.07.2015, i.e. upto 30 Oct., 2016 for 23 Solar PV Power Plants (cumulative capacity 181.40 MW).
AND
In the Matter of:
Uttarakhand Renewable Energy Development Agency ...Petitioner
AND
In the Matter of:
Uttarakhand Power Corporation Ltd. ... Respondent
26.02.2016
In the Matter of:
Suo-Moto proceedings on non-compliance of Renewable Purchase Obligation (RPO) by UPCL in accordance with UERC (Compliance of Renewable Purchase Obligation) Regulations, 2010 & UERC (Tariff and Other Terms for Supply of Electricity from Renewable Energy Sources and non-fossil fuel based Co-generating Stations) Regulations, 2013.
AND
In the Matter of:
1. Sh. S.K. Tamta,
Chief Engineer Level-1 (Comml.),
Uttarakhand Power Corporation Ltd.
Dehradun.
2. Sh. A.K. Singh,
Chief Engineer (Pro. & Comml.),
Uttarakhand Power Corporation Ltd.
Dehradun.
3. Sh. Sunil Vaid,
Suprerintending Engineer (Comml.),
Uttarakhand Power Corporation Ltd.,
Dehradun.
4. Sh. Pravesh Kumar,
Executive Engineer (Comml.),
Uttarakhand Power Corporation Ltd.,
Dehradun.
5. Sh. Munish Chandra,
Executive Engineer (Attached to MD),
Uttarakhand Power Corporation Ltd.,
Dehradun.
6. Ms. Sandhya Ojha,
Assistant Engineer (Comml.),
Uttarakhand Power Corporation Ltd.,
Dehradun.
... Respondents
19.01.2016
In the Matter of:
Investment Approval for Projects covering the construction of 16 Nos. 33/11 kV substation and their associated lines of 131.34 Km.
AND In the Matter of:
Uttarakhand Power Corporaton Ltd. (UPCL) Victoria Cross Vijeta Gabar Singh Bhawan, Kanwali Road, Dehradun. …....Petitioner
19.01.2016
In the Matter of:
Petition for determination of levelised tariff for Rooftop and Small Solar PV Power Plant as per the revised subsidy.
In the Matter of:
Uttarakhand Renewable Energy Development Agency … Petitioner
AND In the Matter of:
Uttarakhand Power Corporation Ltd. ... Respondent
08.01.2016
In the Matter of:
Application seeking approval of UERC on the Draft Power Purchase Agreement between UPCL & Gamma Infraprop (P) Ltd.
In the Matter of:
Uttarakhand Power Corporation Ltd. …Petitioner
M/s Gamma Infraprop (P) Ltd. ...Respondent No. 1
Power Transmission Corporation of Uttarakhand Limited ...Respondent No. 2
08.01.2016
In the Matter of:
Petition under Section 62 & Section 86(1)(a) of the Electricity Act, 2003, read with the UERC (Terms & Conditions for Determination of Tariff) Regulations, 2011 and UERC (Terms & Conditions for Determination of Multi Year Tariff) Regulations, 2015 for determination of tariff for FY 2015- 16 & for the control period from FY 2016-17 till FY 2018-19 for supply of power to UPCL from 214 MW Gas based Kashipur Combined Cycle Power Plant of Gama Infraprop Pvt. Ltd. At Mahukhedaganj, Kashipur, Dist. Udhamsingh Nagar.
In the Matter of:
M/s Gamma Infraprop (P) Ltd. …Petitioner
Uttarakhand Power Corporation Ltd. ...Respondent No. 1
Power Transmission Corporation of Uttarakhand Limited ...Respondent No. 2
08.01.2016
In the Matter of:
Application seeking approval of UERC on the Draft Power Purchase Agreement between UPCL & Selected bidders for setting of Grid Connected Solar PV Power Projects.
In the Matter of:
Uttarakhand Power Corporation Ltd. …Petitioner
Uttarakhand Renewable Energy Development Agency ...Respondent
08.12.2015
In the Matter of:
Suo-Moto proceedings on non-compliance of Renewable Purchase Obligation (RPO) by UPCL in accordance with UERC (Compliance of Renewable Purchase Obligation) Regulations, 2010 & UERC (Tariff and Other Terms for Supply of Electricity from Renewable Energy Sources and non-fossil fuel based Co-generating Stations) Regulations, 2013.
In the Matter of:
Uttarakhand Power Corporation Ltd. …Respondent
08.12.2015
In the Matter of:
Petition for seeking carry forward of Renewable Purchase Obligation of FY 2014-15 amounting to 526.8 MU (Non-Solar) and 2.5 MU (Solar) as per the provisions of UERC (Compliance of Renewable Purchase Obligation) Regulations, 2010.
In the Matter of:
Uttarakhand Power Corporation Ltd. …Petitioner
And In the Matter of:
Uttarakhand Renewable Energy Development Agency ...Respondent
08.12.2015
In the Matter of:
Petition filed under Regulation 27(2) and 41 of the UERC (Terms and Conditions of Intra-State Open Access) Regulations, 2015 read with Regulations 59 of UERC (Conduct of Business) Regulations, 2014 for seeking approval for fixing the cost of ABT check meters.
And In the Matter of: Uttarakhand Power Corporation Ltd. (UPCL) …..…Petitioner
And
1. M/s BST Textile Mills Pvt. Ltd., Udham Singh Nagar
2. M/s Rukmani Iron Pvt. Ltd., Haridwar
3. M/s Alps Industries Ltd., Haridwar …..… Respondents
08.12.2015
In the Matter of:
Investment Approval for increasing capacity of 220 kV Sub-station Chamba from 2x25 MVA (220/33kV) to 1x50 MVA +1x25 MVA (220/33 kV).
And Power Transmission Corporation of Uttarakhand Limited (PTCUL) ....Petitioner Vidyut Bhawan, Near ISBT Crossing, Saharanpur Road, Majra, Dehradun
20.11.2015
In the Matter of:
Petition under Sections 62 and 86(1)(a) of the Electricity Act, 2003 read with the relevant provisions of UERC (Terms & Conditions for Determination of Tariff) Regulations, 2011, UERC (Terms & Conditions for Determination of Multi Year Tariff) Regulations, 2015 for determination of tariff for supply of power from the Petitioner’s 70 MW Hydro - electric power project to UPCL. In the Matter of:
M/s Greenko Budhil Hydro Power Pvt. Ltd. … Petitioner
And In the Matter of:
Uttarakhand Power Corporation Ltd. … Respondent
17.11.2015
In the Matter of:
Prior approval of ‘Capital Investment for Renovation & Modernization’ of Dhalipur (3x17 MW) HEP of UJVN Ltd.
And In the Matter of: UJVN Ltd. ....Petitioner "UJJWAL", Maharani Bhagh, GMS Road, Dehradun
17.11.2015
In the Matter of:
Petition for review of the Hon’ble UERC’s order dated 30.07.2015 on "Petition for prior approval of Capital Investment for Renovation & Modernization of 3 x 30 MW MB-I HEP of UJVN Ltd".
AND
In the Matter of: UJVN Ltd., Dehradun ……...Petitioner
17.11.2015
In the Matter of:
System strengthening of 132 kV S/s Kichha Comprising of:
a. Augmentation of 132/33 kV transformer capacity at 132 kV S/s Kichha from 2x40 MVA to 3x40 MVA including construction of associated 01 no. 132 kV bay and 01 no. 33 kV bay and bisection of 33 kV main bus.
b. Construction of 01 no. Bus Coupler bay using hybrid switchgear and bisection of existing 132 kV main bus.
c. Proposal for ampacity increment of 132 kV Pantnagar-Rudrapur circuit (7.6 Kms.) by replacing for existing ACSR Panther conductor with high capacity ACCC Casablanca conductor.
AND
In the Matter of:: Power Transmission Corporation of Uttarakhand Limited (PTCUL) ....Petitioner Vidyut Bhawan, Near ISBT Crossing, Saharanpur Road, Majra, Dehradun
17.11.2015
In the Matter of:
Investment Approval for Augmentation of Transformer capacity of 132 kV substation Bhupatwala Haridwar from 2x40 MVA to 3x40 MVA by procurement, erection & commissioning of 01 No. 132/33 kV 40 MVA Transformer and construction of 03 Nos. 33 kV Bays at 132 kV substation Bhupatwala Haridwar.
AND
In the Matter of: Power Transmission Corporation of Uttarakhand Limited (PTCUL) ....Petitioner Vidyut Bhawan, Near ISBT Crossing, Saharanpur Road, Majra, Dehradun
17.11.2015
In the Matter of:
Investment Approval for Augmentation of 220 kV Substation Jhajhra from 2x40 MVA to 2x80 MVA.
AND
In the Matter of:
Power Transmission Corporation of Uttarakhand Limited (PTCUL) ....Petitioner Vidyut Bhawan, Near ISBT Crossing, Saharanpur Road, Majra, Dehradun
17.11.2015
In the Matter of:
Investment Approval for Increasing capacity of 220 kV Substation Virbhadra Rishikesh from 2x160 MVA (220/132 kV) to 3x160 MVA (132/33 kV).
AND
In the Matter of:
Power Transmission Corporation of Uttarakhand Limited (PTCUL) ....Petitioner Vidyut Bhawan, Near ISBT Crossing, Saharanpur Road, Majra, Dehradun
17.11.2015
In the Matter of:
Petition for Review of the UERC’s Order dated 11.04.2015 on "True-up of FY 2013-14, Annual Performance Review for FY 2014-15 and Annual Fixed Charges for FY 2015-16 for UJVN Ltd".
AND
In the Matter of:
UJVN Ltd. Dehradun …..Petitioner &
1. Uttarakhand Power Corporation Ltd. (UPCL)
2. Himachal Pradesh State Electricity Board Ltd. (HPSEB Ltd.)
Vidyut Bhawan, Kumar House, Shimla (H.P.) …..Respondents
17.11.2015
In the Matter of:
Review filed by UJVN Ltd. on Commission’s Order dated 13.03.2015 issued in the matter of prior approval of Capital Investment for Renovation & Modernization of 3x10 MW Kulhal HEP. And
In the Matter of: UJVN Ltd. …....Petitioner
17.11.2015
In the Matter of:
Application seeking approval of the Fuel Charge Adjustment (FCA) to be charged from the consumers for the period from 01.10.2015 to 31.12.2015.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
15.10.2015
In the Matter of:
Application seeking approval of UERC on the Draft Power Purchase Agreement between UPCL & M/s Greenko Budhil Hydro Power Pvt. Ltd.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
AND
In the Matter of:
M/s Greenko Budhil Hydro Power Pvt. Ltd. … Respondent
15.10.2015
In the Matter of:
Application seeking approval of the Commission on the Draft Power Purchase Agreement between UPCL & M/s GMR Chhattisgarh Energy Ltd.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
AND
In the Matter of:
M/s GMR Chhattisgarh Energy Ltd. … Respondent
24.09.2015
In the Matter of:
Petition seeking the approval of the Commission for advance banking of power by the UPCL from Haryana Power Purchase Centre/Northern Region Utility, through a trader.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
22.09.2015
In the Matter of:
Petitions filed under section 61 and 86 of the Electricity Act, 2003 read with the relevant regulations and guidelines of the Commission by UJVN Ltd. for approval of Capital investment for:
1. Special Repair Works of Civil & Hydro Mechanical Structures for Yamuna Hydel Scheme Stage-I, II Part-I & IV
2. Refurbishing of Ichari Dam
3. Refurbishing of Dakpathar Barrage
4. Refurbishing of Asan Barrage
AND
In the Matter of:
UJVN Limited …Petitioner
&
Uttarakhand Power Corporation Ltd. (UPCL) … Respondent No. 1
Himachal Pradesh State Electricity Board Ltd. (HPSEBL) … Respondent No. 2
Vidyut Bhawan, Kumar House, Shimla, (H.P.)
22.09.2015
In the Matter of:
Petition filed under Regulation 27(2) and 41 of the UERC (Terms and Conditions of Intra-state open access) Regulations, 2015 read with Regulation 59 of UERC (Conduct of Business) Regulations,2014 for seeking approval for fixing the cost of ABT Check Meter.
AND
In the Matter of:
Uttarakhand Power Corporation Limited (UPCL) ....Petitioner
22.09.2015
In the Matter of:
Petition seeking adjustment of Tariff for Motighat SHP (5 MW) due to Additional Capitalization incurred on account of damages due to natural calamity as per UERC Tariff Regulations, 2010.
In the Matter of:
M/s Himalaya Hydro Pvt. Ltd. … Petitioner
AND
In the Matter of:
Uttarakhand Power Corporation Ltd. ... Respondent
22.09.2015
In the Matter of:
Application seeking approval of the Commission on the Power Purchase Agreement between UPCL and Generators.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
AND
1. M/s Parvatiya Power Pvt. Ltd.
2. M/s S.R. Solar Energy Park.
3. M/s Om Prakash Agarwal.
4. M/s S.K. Solar Power.
5. M/s Raj Kumar.
6. Shri Ubedur Rehaman-proprietor USA Solar Systems.
7. M/s Sourabh Arora.
8. M/s Ashok Aneja.
9. M/s Anil Kumar Gupta.
10. M/s UJVN Ltd.
11. M/s KLA Foods India Ltd.
12. M/s Puran Chand.
13. M/s Dovetail Woodcrafters Pvt. Ltd. ... Respondents
18.08.2015
In the Matter of:
Petition under "UERC (RE) Regulations, 2008" for relief against excess rebate deduction from payment of monthly energy bill of M/s RBNS Sugar Mills Ltd., Laksar, Haridwar by UPCL.
&
Petition under Section 86(1)(f) of the Electricity Act, 2003 for adjudication of the disputes between M/s Swasti Power Ltd. and Uttarakhand Power Corp. Ltd. arising out of the Power Purchase Agreement dated 03.07.2009.
In the Matter of:
M/s Rai Bahadur Narain Singh Sugar Mills Ltd.
M/s Swasti Power Ltd. ….. Petitioners
AND
In the Matter of:
Uttarakhand Power Corporation Ltd. ..... Respondent
18.08.2015
In the Matter of:
Application seeking approval of the Fuel Charge Adjustment (FCA) for the quarter ending June, 2015 and to adjust the same in the FCA computation for the quarter ending September, 2015.
AND
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
18.08.2015
In the Matter of:
Petition under Section 86(1)(f) of the Electricity Act, 2003 for adjudication of the
disputes between M/s Swasti Power Ltd. and Uttarakhand Power Corporation Ltd. arising out of the Power Purchase Agreement dated 03.07.2009 being the loss suffered by the Petitioner on account of frequent outages and inadequate transmission line capacity for evacuation of power from the project.
AND
In the Matter of:
M/s Swasti Power Limited ....Petitioner
111, Road No. 72, Jubilee Hills, Hyderabad
&
In the Matter of:
Uttarakhand Power Corporation Limited (UPCL) ....Respondent 1
Victoria Cross Vijeta Gabar Singh Bhawan, Kanwali Road,
Balliwala Chowk, Dehradun
Power Transmission Corporation of Uttarakhand Limited (PTCUL)..Respondent 2
Vidyut Bhawan, Near ISBT Crossing, Saharanpur Road,
Majra, Dehradun
04.08.2015
In the Matter of:
Investment approval for strengthening of 132 kV network (A) Extension of 220
kV substation Piran Kaliyar (B) Construction of 132 kV LILO of Bhagwanpur-
Chudiyala.
In the Matter of:
Power Transmission Corporation of Uttarakhand Limited (PTCUL).. Petitioner
04.08.2015
In the Matter of:
Investment approval for construction of 220 kV Pirankaliyar-Puhana (PGCIL)
Line.
AND
In the Matter of:
Power Transmission Corporation of Uttarakhand Limited (PTCUL….. Petitioner
30.07.2015
In the Matter of:
Revision filed under Rule 3 Sub-Rule (3) of The Work of Licensee Rule 2006 on the Order dated 02.05.2015 issued by the District Magistrate Udhamsingh Nagar (Uttarakhand), under Rule 3 Sub-Rule 2 of The Work of Licensee Rules, 2006 on the representation of Mr. Suresh Kumar Mittal.
AND
In the Matter of:
1. Uttarakhand Power Corporation Ltd., Urja Bhawan, Kanwali Road, Dehradun, Uttarakhand, through its Director (Projects).
2. Executive Engineer (UPCL), EDD, Sitarganj, District-Udhamsingh Nagar, Uttarakhand
….....…….. Revisionists/Petitioners
&
1. District Magistrate/Collector, District-Udhamsingh Nagar, Uttarakhand
2. Suresh Kumar Mittal S/o Late Sh. Mangatram, R/o Ward No. 4, Khatima, Tehsil Khatima, District Udhamsingh Nagar.……….. Respondents
23.07.2015
In the Matter of:
Compliance of Commission’s orders dated 07.11.2014 and 10.02.2015 in the matter of approval of Power Purchase Agreements between UPCL and Generators.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Applicant
AND
1. M/s Metro Frozen Fruits & Vegetables Pvt. Ltd.
2. M/s Uttam Sugar Mills Ltd.
3. M/s Gunsola Hydro Power Generation (Pvt.) Ltd.
4. M/s RV Akash Ganga Infrastructure Ltd.
5. M/s Jay Ace Technologies Ltd.
6. M/s Regency Aquaelectro & Motelresorts Ltd.
7. M/s Himalaya Hydro Pvt. Ltd. .. Respondents
23.07.2015
In the Matter of:
Application seeking approval of the Commission on the PPAs between UPCL and 08 nos. Generators.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
AND
1. M/s R.C. Energy
2. M/s Purshotam Industries Ltd.
3. M/s Purshotam Ispat
4. M/s Vivan Solar Pvt. Ltd.
5. M/s Uttar Bharat Hydro Pvt. Ltd.
6. M/s Root Hydrocarbons Ltd.
7. M/s Madhav Infra Projects Ltd.
8. UJVN Ltd. ... Respondents
AND
Misc. Appl. Nos. 31/2015 to 34/2015
In the matter of:
Application seeking approval of the Commission on the PPAs between UPCL and 04 nos. Generators.
In the matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
AND
1. M/s Eastman International
2. M/s Advika Energies Pvt. Ltd.
3. M/s Redwoods Infrastructure Pvt. Ltd.
4. UJVN Ltd. ... Respondents
02.07.2015
In the Matter of:
Grid connectivity for 12.6 MW SHP of M/s Uttar Bharat Hydro Power Pvt. Ltd., New Delhi(Suo-moto).
AND
In the Matter of:
Uttarakhand Power Corporation Limited (UPCL) ....Respondent 1
M/s Uttar Bharat Hydro Power Pvt. Ltd. ….Respondent 2
02.07.2015
In the Matter of:
Petition under Section 30, 42(2), 42(3) and 86(1)(c) of the Electricity Act, 2003 read with Regulation 41 of Uttarakhand Electricity Regulatory Commission (Terms and Conditions of Intra-state Open Access) Regulations, 2015 for removal of difficulty in giving effect to the provisions regarding grant of Open Access to the Petitioner.
AND
In the Matter of:
M/s Shree Cement Limited.
Akbarpur Oud, Laksar, District-Haridwar, Uttarakhand ....Petitioner
& In the Matter of:
Uttarakhand Power Corporation Limited (UPCL) ....Respondent 1
State Load Dispatch Centre (SLDC) ....Respondent 2
02.06.2015
In the Matter of:
Implementation of Retail Tariff Order issued by the Commission on 11.04.2015.
AND
In the Matter of:
Uttarakhand Power Corporation Ltd. … Applicant
02.06.2015
In the Matter of:
Petition seeking extension of generic tariff prescribed under the UERC (Tariff and Other Terms for Supply of Electricity from Renewable Energy Sources and non-fossil fuel based Co-generating Stations) Regulations, 2013 till August 31, 2015 and seeking framing of procedure for promotion of solar plants.
In the Matter of:
M/s Amplus Infrastructure Developers Pvt. Ltd.
M/s Avant Garde Power Solutions Pvt. Ltd.
M/s Rishabh Renergy Pvt. Ltd. … Applicants
AND
In the Matter of:
Uttarakhand Power Corporation Ltd.
Uttarakhand Renewable Energy Development Agency (UREDA) ... Respondents
12.05.2015
In the Matter of:
Misc. Petition under "UERC (Tariff & Other Terms for Supply of Electricity from NRE Sources) Regulation 2008" for relief against Excess Rebate deduction from payment of Monthly Energy Bill by the UPCL. In the matter of:
M/s Rai Bahadur Narain Singh Sugar Mills Ltd. … Petitioner
AND
In the Matter of:
Uttarakhand Power Corporation Ltd. … Respondent
12.05.2015
In the Matter of:
Application seeking approval of the Fuel Charge Adjustment (FCA) to be charged from the consumers for the period from 01-04-2015 to 30-06-2015.
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
07.04.2015
In the Matter of:
Determination of project specific tariff for 10.5 MW Small Hydro Power Project on Sarju River at Kapkot, Bageshwar District, Uttarakhand under Sections 62 and 86 of the Electricity Act, 2003 read with Regulation 13 of Uttarakhand Electricity Regulatory Commission (Tariff and Other Terms for Supply of Electricity from Non-conventional and Renewable Energy Sources) Regulations, 2013.
In the Matter of:
M/s Uttar Bharat Hydro Power Pvt. Ltd. … Petitioner
AND
In the Matter of:
Uttarakhand Power Corporation Ltd. ... Respondent
07.04.2015
In the Matter of:
Petition under Section 86 (1) (f) of the Electricity Act, 2003, for adjudication of the disputes between M/s Swasti Power Ltd and Uttarakhand Power Corporation Ltd. arising out of the Power Purchase Agreement dated 03.07.2009 being the loss suffered by the petitioner on account of frequent outages and inadequate transmission line capacity for evacuation of power from the project.
In the Matter of:
M/s Swasti Power Ltd. … Petitioner
AND
In the Matter of:
Uttarakhand Power Corporation Ltd. ... Respondent-I
Power Transmission Corporation of Uttarakhand Ltd. … Respondent-II
07.04.2015
In the Matter of:
Prior approval of “Capital Investment for Renovation & Modernization of 4 x 36 MW Chilla HEP” of UJVN Ltd. under Section 61 and 86 of the Electricity Act, 2003 read with the relevant regulations and guidelines of the Hon’ble Commission.
AND
In the Matter of:
Managing Director, UJVN Ltd., ....Petitioner.
“UJJWAL”, Maharani Bagh, G.M.S. Road, Dehradun.
06.02.2015
In the Matter of:
Misc. App. No. 02 of 2015
1) Investment Approval for construction of 1. (2x25 MVA), 220/33 kV S/s Barham (Jauljivi) and 2. Construction of LILO line of one circuit 220 kV Dhauliganga-Pithoragarh (PGCIL) line at proposed (2x25 MVA), 220/33 kV S/s Barham (Jauljivi) Misc. App. No. 03 of 2015
2) Investment approval for increasing capacity of 132/33 kV S/s Jwalapur from 2x40 MVA to 3x40 MVA.
Power Transmission Corporation of Uttarakhand Ltd. (PTCUL). ...Petitioner
04.02.2015
In the Matter of:
Application seeking approval of the Fuel Charge Adjustment (FCA) to be charged from the consumers for the period from 01.01.2015 to 31.03.2015. In the Matter of: Uttarakhand Power Corporation Ltd. … Petitioner
21.01.2015
In the Matter of: Petition under Section 86(1)(F) of the Electricity Act, 2003 for adjudication of the disputes between M/s Swasti Power Ltd. and Uttarakhand Power Corp. Ltd. arising out of the Power Purchase Agreement dated 03.07.2009. In the matter of: M/s Swasti Power Ltd. … Applicant
21.01.2015
In the Matter of:
Petition seeking waiver and refund of penalty imposed by the Commission vide its Order dated 01.09.2005.
AND
In the Matter of:
Uttarakhand Power Corporation Limited,
Urja Bhawan
, Kanwali Road, Dehradun …Petitioner
20.01.2015
In the Matter of:
(i) Increasing capacity of 220 kV sub-station SIDCUL, Haridwar from 2x80 MVA (132/33 kV) to 2x80 MVA (132/33 KV) + 1x50 MVA (220/33 KV).
(ii) Construction of 132 kV overhead line from 220 kV sub-station SIDCUL Haridwar to 132/33 kV sub-station Jwalapur.
(iii) Construction of 132/33 kV sub-station Chudiyala 2x40 MVA and its line, construction of 6 nos. 132 kV bays and 05 nos. 33 kV bays at Chudiyala.
(iv) Construction of colony at 132 kV sub-station Majra Campus Dehradun.
Power Transmission Corporation of Uttarakhand Ltd. (PTCUL). ...Petitioner
19.01.2015
In the Matter of:
Petition filed by M/s Bhilangana Hydro Power Ltd. for indemnification on account of loss caused due to delay in commissioning of transmission/evacuation system and the breach of the provisions of the transmission services agreements.
M/s Bhilangana Hydro Power Ltd. (BHPL). ...Petitioner
And
Power Transmission Corporation of Uttarakhand Ltd. (PTCUL). ...Respondent
09.01.2015
In the Matter of:
Dispute between UJVN Ltd. and Uttarakhand Power Corporation Limited (UPCL) relating to payments.
AND
In the Matter of:
Managing Director, UJVN Ltd., ....Petitioner
"UJJWAL", Maharani Bagh, G.M.S. Road, Dehradun
AND
Managing Director, Uttarakhand Power Corporation Limited (UPCL) .... Respondent
Victoria Cross Vijeta Gabar Singh Bhawan, Kanwali Road, Dehradun
09.01.2015
In the Matter of: Applications seeking approval of UERC on the Power Purchase Agreement between Uttarakhand Power Corporation Ltd. and Himalaya Hydro Pvt. Ltd., Regency Yamuna Energy Ltd. & Regency Aquaelectro & Motelresorts Ltd.
AND
In the matter of: Uttarakhand Power Corporation Ltd. ... Petitioner
AND
In the Matter of:
M/s Himalaya Hydro Pvt. Ltd.
M/s Regency Yamuna Energy Ltd.
M/s Regency Aquaelectro & Motelresorts Ltd. … Respondents
22.12.2014
In the Matter of:
Filing of petition for re-determination of Generic Tariff for Pathri Small Hydro Generating Station (3x6.8 MW) & Mohammadpur Small Hydro Generating Station (3x3.1 MW) of UJVN Ltd. under Section 62, 86 and 94(1)(f) of the Electricity Act, 2003 read with the relevant Regulations, Orders and Guidelines of the Commission.
And In the Matter of:
UJVN Ltd. … Petitioner
And In the Matter of:
Uttarakhand Power Corporation Ltd. ... Respondent
22.12.2014
In the Matter of:
Petition under Section 86(1)(f) read with Section 142 of the Electricity Act, 2003 for Recovery of deemed generation charges from UPCL for the Financial Year 2012-2013 and Financial Year 2013-2014 in accordance with Regulation 44 of UERC(Tariff and Other Terms for Supply of Electricity from Non-conventional and Renewable Energy Sources) (First Amendment) Regulations, 2012.
And In the Matter of:
M/s Birahi Ganga Hydro Power Ltd. … Petitioner
And In the Matter of:
Uttarakhand Power Corporation Ltd. ... Respondent
27.11.2014
In the Matter of:
Proceeding initiated in the Commission’s Order dated 08.07.2014 under section 142 of the Electricity Act, 2003 for non-compliance of the provisions of the section 67 & 68 of the Electricity Act, 2003 in the matter of M/s Birla Tyres, Unit II, Khedimubarakpur, Laksar Haridwar.
And In the Matter of:
Power Transmission Corporation of Uttarakhand Limited (PTCUL) .... Respondent
27.11.2014
In the Matter of:
Petition to wave the token Penalty of Rs. 10,000/- imposed under Section 142 of the Electricity
Act, 2003 for non compliance, vide Order dated 9th September, 2014 passed by Hon’ble
Commission in the matter of Notice issued to MD, UPCL under Section 142 of the Electricity
Act, 2003 in the matter of non-compliance of the Commission’s Order dated 24.06.2014 on the
Review Petition filed by UPCL on Commission’s Order dated 05.05.2014 on the application
seeking approval of releasing additional 6 MVA load(Total of 20MVA) on supply voltage of 33
kv to M/s Birla Tyres, Unit-II, Khedimubarakpur, Laksar, Haridwar. And In the Matter of:
Managing Director, Uttarakhand Power Corporation Limited (UPCL).... Petitioner
27.11.2014
In the Matter of:
Petition with regard to Investment Approval for construction of well foundations and tower protection works at different locations of 220 kV DC Twin Zebra transmission line from 220 kV S/s Dehradun (PTCUL) to 400 kV S/s Sherpur, Dehradun of PGCIL.
Power Transmission Corporation of Uttarakhand Limited (PTCUL) ...Petitioner In the Matter of:
Petition seeking waiver and refund of penalty imposed by the Commission vide its Order dated 01.09.2005.
AND In the Matter of:
Uttarakhand Power Corporation Limited, Urja Bhawan, Kanwali Road, Dehradun …Petitioner
27.11.2014
In the Matter of:
Petition seeking waiver and refund of penalty imposed by the Commission vide its Order dated 01.09.2005. AND In the Matter of:
Uttarakhand Power Corporation Limited, Urja Bhawan, Kanwali Road, Dehradun …Petitioner
14.10.2014
In the Matter of:
Petition seeking approval for the Investment on Dehradun Project covering the woks covered under Part-B of R-APDRP of MoP, GoI for reduction of AT&C losses to the extent of 15%.
AND In the Matter of:
Uttarakhand Power Corporation Limited (UPCL) .... Petitioner
14.10.2014
In the Matter of:
Petition seeking approval for Investment on SCADA/DMS Project of Dehradun town covered under Part-A of R-APDRP of MoP GoI.
AND In the Matter of:
Uttarakhand Power Corporation Limited (UPCL) .... Petitioner
14.10.2014
In the Matter of:
Petition for in-principle approval of Capital Expenditure for Balance Capital Works of 4x76 MW MB-II HEP of UJVN Ltd.
AND In the Matter of:
UJVN Limited .... Petitioner
14.10.2014
In the Matter of:
Petition for prior approval of Capital investment for Renovation & Modernization of MB-I (3x30 MW) HEP of UJVN Ltd.
AND In the Matter of:
UJVN Limited .... Petitioner
14.10.2014
In the Matter of:
Show cause notices dated 28.07.2014 issued to Sh. Kamal Kant, Chief Engineer (C&R) & Sh. A.K. Agarwal, Superintending Engineer (Engg.), PTCUL.
In the Matter of:
1. Sh. Kamal Kant, Chief Engineer (C&R), PTCUL
2. Sh. A.K. Agarwal, Superintending Engineer (Engg.), PTCUL …Respondents
14.10.2014
In the Matter of:
Application seeking review of the Tariff Order issued by the Hon’ble Commission on 10.04.2014 on the Annual Performance Review and Tariff petition of UPCL for F.Y. 2014-2015.
In the Matter of:
Uttarakhand Power Corporation Ltd. ... Petitioner
13.10.2014
In the Matter of:
Petition seeking amendments in the PPA dated 30.11.2010 executed between Birahi Ganga Hydro Power Ltd. and UPCL in accordance with the provisions of UERC (Tariff and Other Terms for Supply of Electricity from Non-conventional and Renewable Energy Sources) Regulations, 2010, Removal of Difficulty (First) Order, 2010 and CERC (Terms and Conditions of Tariff) Regulations, 2014.
In the Matter of:
M/s Birahi Ganga Hydro Power Ltd. … Petitioner
AND
Uttarakhand Power Corporation Ltd. ... Respondent
AND
Petition No. 21 of 2014
In the matter of:
Uttarakhand Power Corporation Ltd. ... Petitioner
AND
1. M/s Metro Frozen Fruits & Vegetables Pvt. Ltd ... Respondents
2. M/s Birahi Ganga Hydro Power Ltd.
3. M/s Gunsola Hydro Power Generation (Pvt.) Ltd.
4. M/s Chamoli Hydro Power Pvt. Ltd.
5. M/s Swasti Power Ltd.
6. M/s Rai Bhadur Narain Singh Sugar Mills Ltd.
7. M/s Rishiganga Power Corporation Ltd.
8. M/s RV Akash Ganga Infrastructure Ltd.
9. M/s Uttam Sugar Mills Ltd.
10. M/s Lakshmi Sugar Mills Co. Ltd.
11. M/s Jay Ace Technologies Ltd.
01.10.2014
In the Matter of:
1. Petition for approval of Capital investment for Refurbishing of Asan Barrage of UJVN Ltd. under section 61 and 86 of the Electricity Act, 2003 read with the relevant regulations and guidelines of the Commission.
2. Petition for approval of Capital investment for Refurbishing of Dakpathar
Barrage of UJVN Ltd. under section 61 and 86 of the Electricity Act, 2003 read with the relevant regulations and guidelines of the Commission.
3. Petition for approval of Capital investment for Special Repair Works of Civil & Hydro Mechanical Structures for Yamuna Hydel Scheme Stage-I, II Part-I & IV of UJVN Ltd. under section 61 and 86 of the Electricity Act, 2003 read with the relevant regulations and guidelines of the Commission.
4. Petition for approval of Capital investment for Refurbishing of Ichari Dam of UJVN Ltd. under section 61 and 86 of the Electricity Act, 2003 read with the relevant regulations and guidelines of the Commission.
AND
In the Matter of:
UJVN Limited .... Petitioner
24.09.2014
In the Matter of:
Application seeking approval of Hon’ble UERC for the investment on the projects covering the construction of 14 No. 33/11 kV Substation and their associated lines of 113.70 Km.
AND
In the Matter of:
Uttarakhand Power Corporation Limited (UPCL) .... Petitioner
12.09.2014
In the Matter of:
Suo-moto proceedings initiated by the Commission for non-issuance of NOC by UPCL for Open Access.
AND
In the Matter of:
Petition filed by M/s Kashi Vishwanath Steel Ltd, Narain Nagar Industrial Estate, Kashipur with regard to removal of difficulty under Regulation 58 of UERC (Terms and Condition of Intra-State Open Access) Regulations, 2010. ....Petitioner
AND
Uttarakhand Power Corporation Ltd. (UPCL). ...Respondent
12.09.2014
In the Matter of:
Notice under section 142 of the Electricity Act, 2003 in the matter of non-compliance of the provisions of Section 67 read with Section 12 of the Indian Electricity Act, 1910, 68 & 164 of the Electricity Act, 2003 (in the matter of M/s Gold Plus).
AND
In the Matter of:
Managing Director, .... Respondent
Power Transmission Corporation of Uttarakhand Limited (PTCUL)
02.09.2014
In the Matter of:
Revision filed under Rule 3 Sub-Rule (3) of The Work of Licensee Rule 2006 on the Order dated 20.05.2014 issued by the District Magistrate Udhamsingh Nagar (Uttarakhand), under Rule 3 Sub-Rule 2 of The Work of Licensee Rules, 2006 on the representation of Mr. Suresh Kumar Mittal.
AND
In the Matter of:
1) Uttarakhand Power Corporation Ltd., Urja Bhawan, Kanwali Road, Dehradun, Uttarakhand, through its Managing Director. 2) Executive Engineer (UPCL), EDD, Sitarganj, District-Udhamsingh Nagar, Uttarakhand ... Petitioner
AND
1) District Magistrate/Collector, District-Udhamsingh Nagar, Uttarakhand
2) Sh. Suresh Kumar Mittal S/o Late Sh. Mangatram, R/o Ward No. 4, Khatima, Tehsil Khatima, District Udhamsingh Nagar. … Respondents
19.08.2014
In the Matter of:
Application seeking review of the Tariff Order issued by the Hon’ble Commission on 10.04.2014 on the Annual Performance Review and Tariff petition of UPCL for F.Y. 2014-2015.
In the Matter of:
Uttarakhand Power Corporation Limited ….. Petitioner
19.08.2014
In the Matter of:
Review petition filed under regulation 68 of the UERC(Conduct of Business Regulations,2004 for review of the order dated April10, 2014 passed by the UERC with respect to determination of tariff of M/s Him Urja Pvt. Ltd.’s Vanala Small Hydro Project of 15 MW Capacity In the Matter of:
Uttarakhand Power Corporation Limited Petitioner
AND
In the Matter of:
M/s Him Urja Pvt. Ltd. Respondent
14.08.2014
In the Matter of:
Petition for clarification on various issues for implementation of “Uttarakhand Grid Interacted Rooftop and Small SPV Power Plants Scheme”.
In the Matter of:
Uttarakhand Renewable Energy Development Agency … Petitioner
AND
In the Matter of:
Uttarakhand Power Corporation Ltd. ... Respondent
12.08.2014
In the Matter of:
Notice issued to MD, UPCL under Section 142 of the Electricity Act, 2003 in the matter of
non-compliance of the Commission’s Order dated 24.06.2014 on the Review Petition filed by UPCL on Commission’s Order dated 05.05.2014 on the application seeking approval of releasing additional 6 MVA load (Total of 20 MVA) on supply voltage of 33 kV to M/s BirlaTyres, Unit-II, Khedimubarakpur, Laksar, Haridwar.
AND
In the Matter of:
Managing Director, Uttarakhand Power Corporation Limited (UPCL) .... Respondent
12.08.2014
In the Matter of:
In the Matter of:
Notice issued to MD, UPCL under Section 43(3) of the Electricity Act, 2003 in the matter of violation of the provisions of section 43(1) of the Electricity Act, 2003
& Inordinate delay in release of additional 10 MVA load to M/s Birla Tyres, Unit-II,
Khedimubarakpur, Laksar, Haridwar.
AND
In the Matter of:
Managing Director, Uttarakhand Power Corporation Limited (UPCL) .... Respondent
12.08.2014
In the Matter of:
Petition for seeking carry forward of Renewable Purchase Obligation for FY 2013-14 amounting to 387.68 MU (Non-Solar) and 1.08 MU (Solar) as per the provisions of UERC (Compliance of Renewable Purchase Obligation) Regulations, 2010.
AND
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
12.08.2014
In the Matter of:
Application seeking approval of UERC on the wrongful & impugned decision by Uttarakhand Power Corporation Ltd. (UPCL) regarding cost sharing of Rajstar/Gangani Sub Station as per MoU signed by UPCL & Regency Gangani Energy Pvt. Ltd. on 23rd July, 2009.
AND
In the Matter of:
M/s Regency Gangani Energy Pvt. Ltd. … Petitioner
AND
In the Matter of:
Uttarakhand Power Corporation Ltd. ... Respondent
12.08.2014
In the Matter of:
Petition seeking amendments in the PPA dated 30.11.2010 executed between Birahi Ganga Hydro Power Ltd. And UPCL in accordance with the provisions of UERC (Tariff and other Terms for Supply of Electricity from Non-Conventional and Renewable Energy sources) Regulations,2010, Removal of difficulty (First) Order 2010 and CERC (Terms and Conditions of Tariff) Regulations 2014.
AND
In the Matter of:
M/s Birahi Ganga Hydro Power Ltd. … Petitioner
AND
In the Matter of:
Uttarakhand Power Corporation Ltd. ... Respondent
28.07.2014
In the Matter of:
Application seeking post facto approval of the Fuel Charge Adjustment (FCA) to be charged from the consumers for the period from 01-07-2014 to 30-09-2014.
AND
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
24.07.2014
In the Matter of:
Petition for seeking carry forward of Renewable Purchase Obligation for FY 2013-14 amounting to 387.68 MU (Non-Solar) and 1.08 MU (Solar) as per the provisions of UERC (Compliance of Renewable Purchase Obligation) Regulations, 2010.
AND
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
AND
In the Matter of:
Uttarakhand Renewable Energy Development Agency ... Respondent
15.07.2014
In the Matter of:
Application seeking approval of UERC on the wrongful & impugned decision by Uttarakhand Power Corporation Ltd. (UPCL) regarding cost sharing of Rajstar/Gangani Sub Station as per MoU signed by UPCL & Regency Gangani Energy Pvt. Ltd. on 23rd July, 2009.
AND
In the Matter of:
M/s Regency Gangani Energy Pvt. Ltd. … Petitioner
AND
Uttarakhand Power Corporation Ltd. ... Respondent
15.07.2014
In the Matter of:
Application seeking approval of Uttarakhand Electricity Regulatory Commission on the Draft Power Purchase Agreement between Uttarakhand Power Corporation and M/s Regency Yamuna Energy Ltd. for Badyar SHP. AND
In the Matter of:
Uttarakhand Power Corporation Ltd. … Petitioner
AND
In the Matter of:
M/s Regency Gangani Energy Pvt. Ltd. ... Respondent
10.07.2014
In the Matter of:
Application under Section 42(2) of the Electricity Act, 2003 read with Regulation 58 of the UERC (Terms and Conditions of Intra-State Open Access) Regulations, 2010 for clarification on the aspect of payment for under-drawal.
AND
In the Matter of:
Shree Cement Ltd. Bangur Nagar, Post Box No. 33, Beawar-305901 (Raj) ...Petitioner
AND
Managing Director, Uttarakhand Power Corporation Limited (UPCL) …Respondent
Victoria Cross Vijeta Gabar Singh Bhawan, Kanwali Road, Dehradun
02.07.2014
In the Matter of:
In the matter of: Application seeking approval of the Commission for the investment on the project covering construction of 44.1 km, 33 kV line to connect 7 Nos. 33/11 kV Sub-station to 220/33 kV Sub-station Jhajhra.
AND
In the Matter of: Uttarakhand Power Corporation Limited (UPCL) .... Petitioner
01.07.2014
In the Matter of:
In the matter of: Filing of proposal for prior approval of "Capital Investment for Renovation & Modernization of 3 x 10 MW Kulhal HEP" of UJVN Ltd. under Section 61 and 86 of the Electricity Act, 2003 read with the relevant regulations and guidelines of the Hon’ble Commission.
AND
In the Matter of: UJVN Ltd., Dehradun ….Petitioner.
24.06.2014
In the Matter of:
Review Petition on the Commission’s Order dated 05.05.2014 under provisions of the Regulation 68 Regulation 74 of UERC (Conduct of Business) Regulations, 2004 read with the relevant provisions of the Electricity Act, 2003 in the matter application seeking approval of releasing additional 6 MVA load (Total of 20 MVA) on Supply Voltage of 33 kV to M/s Birla Tyres, Unit-2, Hardwar.
AND
In the Matter of:
Uttarakhand Power Corporation Limited (UPCL) ....Petitioner
AND
1. M/s Birla Tyres, Unit-II, Khedi Mubarakpur, Laksar, Haridwar .... Respondent 1
2. Power Transmission Corporation of Uttarakhand Limited (PTCUL) .... Respondent 2
17.06.2014
In the Matter of:
Petition to waive the per day Penalty for non compliance imposed vide order dated 22 January, 2014 passed by the Commission.
AND In the Matter of:
Managing Director, UPCL ….. Petitioner
10.06.2014
In the Matter of:
In the matter of: Application seeking approval for the investment on the projects covering (i) Replacement of ACSR conductor by AB cable in theft prone areas. (ii) Installation of additional transformers.
AND
MD, UPCL.... Petitioner
09.06.2014
In the Matter of:
Petition seeking approval of the Draft Power Purchase Agreement between Uttarakhand Power Corporation Ltd. and M/s Super Hydro Electric Pvt. Ltd.
AND In the Matter of:
Uttarakhand Power Corporation Ltd. Petitioner
AND In the Matter of:
M/s Super Hydro Electric Pvt. Ltd. Respondent No. 1
Power Transmission Corporation Uttarakhand Ltd. Respondent No. 2
09.06.2014
In the Matter of:
Application seeking recovery of claim in respect of Deemed Generation under Section 44 (A) of the UERC (Tariff and Other Terms for Supply of Electricity from Non-conventional and Renewable Energy Sources) Regulations, 2012 and as amended by UERC’s Tariff Regulations of 2013, in accordance with Section 181 of the Electricity Act, 2003.
AND In the Matter of:
M/s Himalaya Hydro Pvt. Ltd. … Petitioner
AND
Uttarakhand Power Corporation Ltd. ... Respondent No. 1
Power Transmission Corporation of Uttarakhand Ltd. ... Respondent No. 2
29.05.2014
In the Matter of:
Petition to waive the per day Penalty for non compliance imposed vide order dated 22 January, 2014 passed by the Commission.
16.05.2014
In the Matter of:
Dispute between UJVN Ltd. and Uttarakhand Power Corporation Limited (UPCL)
relating to payments.
AND In the Matter of:
Managing Director, UJVN Ltd., ....Petitioner
“UJJWAL”, Maharani Bagh, G.M.S. Road, Dehradun
AND
Managing Director, Uttarakhand Power Corporation Limited (UPCL) .... Respondent
Victoria Cross Vijeta Gabar Singh Bhawan, Kanwali Road, Dehradun
16.05.2014
In the Matter of:
Review Petition on the Order dated 16.01.2014 issued by Hon’ble UERC in the matter of
Non-compliance of UERC (Release of New HT & EHT Connections, Enhancement and
Reduction of Loads) Regulations, 2008 and in the matter of M/s Gold Plus Glass Industry
Ltd. Thithola (Roorkee) and Uttarakhand Power Corporation Ltd.
AND In the Matter of:
MD, Power Transmission Corporation of Uttarakhand Limited (PTCUL) .... Petitioner
&
1. M/s Gold Plus Glass Industry Ltd. Thithola (Roorkee) .... Respondent 1
2. MD, Uttarakhand Power Corporation Limited (UPCL) .... Respondent 2
16.05.2014
In the Matter of:
Suo-moto proceedings initiated under section 142 of the Electricity Act, 2003 for Non compliance
of the Commission’s Directions
AND In the Matter of:
Non-implementation of Order dated 09.10.2012 of the Ombudsman (Electricity) in the
matter of IDPL, Virbhadra, Rishikesh
AND
1. MD, Uttarakhand Power Corporation Limited (UPCL) .... Respondent 1
2. General Manager, M/s IDPL, Virbhadra, Rishikesh .... Respondent 2
16.05.2014
In the Matter of:
Non-compliance by UPCL in the matter of directives given to it by the Commission on implementation of Scheme of Prepaid Metering vide Tariff Order dated April 11, 2012 for FY 2012-13.
AND In the Matter of:
Uttarakhand Power Corporation Ltd. … Respondent
06.05.2014
In the Matter of:
Review Petition against the Order dated 16.01.2014 issued by Hon’ble UERC in the matter of Non-compliance of UERC (Release of New HT & EHT Connections, Enhancement and Reduction of Loads) Regulations, 2008 and in the matter of M/s Gold Plus Glass Industry Ltd. Thithola (Roorkee) and Uttarakhand Power Corporation Ltd.
AND In the Matter of:
Power Transmission Corporation of Uttarakhand Limited (PTCUL) .... Petitioner
AND
1. M/s Gold Plus Glass Industry Ltd. Thithola (Roorkee) .... Respondent 1
2. Uttarakhand Power Corporation Limited (UPCL) .... Respondent 2
05.05.2014
In the Matter of:
Application seeking approval of releasing additional 6 MVA load (Total of 20 MVA) on Supply Voltage of 33 kV to M/s Birla Tyres, Unit-2, Hardwar.
AND In the Matter of:
M/s Birla Tyres, Unit-II, Khedi Mubarakpur, Laksar, Haridwar ....Petitioner
AND
1. Uttarakhand Power Corporation Limited (UPCL) .... Respondent 1
2. Power Transmission Corporation of Uttarakhand Limited (PTCUL) .... Respondent 2
06.05.2014
In the Matter of:
Application seeking approval of UERC on the wrongful & impugned decision by Uttarakhand Power Corporation Ltd. (UPCL) regarding cost sharing of Rajstar/Gangani Sub Station as per MoU signed by UPCL & Regency Gangani Energy Pvt. Ltd. on 23rd July, 2009
AND In the Matter of:
M/s Regency Gangani Energy Pvt. Ltd. … Petitioner
AND
Uttarakhand Power Corporation Ltd. ... Respondent
06.05.2014
In the Matter of:
Non-compliance by UPCL in the matter of directives given to it by the Commission on implementation of Scheme of Prepaid Metering vide Tariff Order dated April 11, 2012 for FY 2012-13.
AND In the Matter of:
Uttarakhand Power Corporation Ltd. … Respondent
06.05.2014
In the Matter of:
Application seeking recovery of claim in respect of Deemed Generation under Section 44 (A) of the UERC (Tariff and Other Terms for Supply of Electricity from Non-conventional and Renewable Energy Sources) Regulations, 2012 and as amended by UERC’s Tariff Regulations of 2013, in accordance with Section 181 of the Electricity Act, 2003.
AND In the Matter of:
M/s Himalaya Hydro Pvt. Ltd. … Petitioner AND
Uttarakhand Power Corporation Ltd. ... Respondent No. 1
Power Transmission Corporation of Uttarakhand Ltd. ... Respondent No. 2
23.04.2014
In the Matter of:
Applications filed by PTCUL seeking approval of Investments/Capital Expenditures with regard to Construction of (2x50 MVA) 220/33 kV S/s at Piran Kaliar, Construction of (6x5 MVA) 132 kV GIS S/s at Bageshwar and Construction of (2x20 MVA) 132 kV GIS S/s at Lohaghat due to change in scope of work.
AND In the Matter of:
Power Transmission Corporation of Uttarakhand Ltd. (PTCUL). ...Petitioner
11.04.2014
In the Matter of:
Application seeking approval of releasing additional 6 MVA load (Total of 20 MVA) on Supply Voltage of 33 kV to M/s Birla Tyres, Unit-2, Hardwar.
AND In the Matter of:
M/s Birla Tyres, Unit-II, Khedi Mubarakpur, Laksar, Haridwar ....Petitioner
AND
1. Uttarakhand Power Corporation Limited (UPCL) .... Respondent 1
2. Power Transmission Corporation of Uttarakhand Limited (PTCUL) ...Respondent 2
10.04.2014
In the Matter of:
Approval of Short term power procurement for the month from April 14 to June 14.
AND
Uttarakhand Power Corporation Ltd. (UPCL).
25.03.2014
In the Matter of:
Application filed by M/s Him Urja Pvt. Ltd., New Delhi under UERC (Compliance of Renewable Purchase Obligation) Regulation, 2010 seeking accreditation and issuance of Renewable Energy Certificates for Rajwakti Generating Station.
AND In the Matter of:
M/s Him Urja Pvt. Ltd. … Petitioner
AND In the Matter of:
Uttarakhand Renewable Energy Development Agency
AND
Uttarakhand Power Corporation Ltd. .... Respondents
10.01.2014
In the Matter of:
Application filed by M/s Swasti Power Ltd. seeking for condonation of delay in filing of the petition for determination of Project Specific Tariff in respect of 22.5 MW Bhilangana HEP in Uttarakhand
AND In the Matter of:
M/s Swasti Power Ltd. ...Petitioner
AND In the Matter of:
Uttarakhand Power Corporation Ltd. …Respondent
13.11.2013
In the Matter of:
Suo-moto proceedings initiated by the Commission for non-compliance by UPCL of Section 59 of the Electricity Act, 2003 read with Regulation 5 of UERC (Standard of Performance) Regulations, 2007AND UPCL.
29.10.2013
In the Matter of:
Non-Compliance by UPCL in the matter of directives given to it by the Commission on implementation of Scheme of Prepaid Metering vide Tariff Order dated 11.04.2012 for FY 2012-13.
11.10.2013
In the Matter of: Application seeking waiver and refund of penalty imposed by the Commission vide its Order dated 01.09.2005 AND UPCL.
11.10.2013
In the Matter of:
Non-compliance of UERC (Release of New HT & EHT Connections, Enhancement and
Reduction of Loads) Regulations, 2008.
And In the Matter of:
M/s Gold Plus Glass Industry Ltd., Thithola (Roorkee) ...Petitioner
Vs.
Uttarakhand Power Corporation Limited (UPCL)
Power Transmission Corporation of Uttarakhand Limited (PTCUL) ...Respondents
30.07.2013
In the Matter of:
Petition filed by UJVN Ltd. for review of the Order on Approval of Business Plan and Multi Year Tariff for FY 2013-14 to FY 2015-16.
And In the Matter of:
UJVN Ltd. ….Petitioner
And In the Matter of:
Uttarakhand Power Corporation Ltd. ….Respondent
30.07.2013
In the Matter of:
Non-Compliance by Obligated Entities under UERC (Tariff and Other Terms for Supply of Electricity from non-conventional and Renewable Energy Sources) Regulations, 2010 and UERC (Compliance of Renewable Purchase Obligation) Regulations, 2010.
And In the Matter of:
M/s Tata Motors Pvt Ltd., M/s Purti Textiles, M/s Mahalxmi Polypack Ltd., M/s Air Liquide India Ltd., M/s Rana Bar Ltd., M/s Rana Industries Ltd., M/s Bhavani Industries Ltd., M/s Amul Auto Components Pvt Ltd., Haridwar, M/s Mahabal Auto Pvt. Ltd., M/s Amul Auto Components Pvt Ltd., Unit-II, Pantnagar, M/s U.P. Bone Mills Pvt. Ltd., M/s Amul Auto Components Pvt. Ltd., Unit-II, Haridwar, M/s Sundram Fasteners Ltd., M/s Shriram Foundary Ltd., M/s Mantri Metallic Pvt. Ltd., M/s Shri Grinding Cement Ltd., M/s Ganesha Echosphere Ltd., M/s Ambuja Cement, M/s India Glycols Ltd., M/s Rockman Industries Ltd., M/s Asahi India Glass Ltd., M/s Hindustan National Glass and Industries Ltd., M/s Jaypee Roorkee Cement, M/s DVS Industries Ltd., M/s Rojee Tasha Stamping Ltd., M/s Bajaj Motors Ltd., M/s Anusuya Auto Press Parts Pvt. Ltd., M/s Autocomp Corporation Panes Pvt. Ltd., M/s Shivani Locks Pvt. Ltd., M/s Dali & Samir Engineering Pvt. Ltd., M/s Everest Industries Ltd., M/s Amul Auto Components Pvt Ltd., Pantnagar, M/s Pashupati Polytex Ltd., M/s Pashupati Laminators Ltd., M/s Syndicate Auto Components, M/s Sona Somic, M/s Time Technoplast Ltd., Unit-I, M/s Time Technoplast Ltd., Unit-II, M/s Hindustan Zinc Ltd., Pantnagar, M/s Hindustan Zinc Ltd., Haridwar
...Respondents
Disclaimer: While every care has been taken to ensure the accuracy of information furnished in this website, UERC does not accept any responsibility or liability for any damage or loss to any person for the result of any action taken on the basis of this information. However, UERC shall be obliged if errors/omissions are brought to its notice for carrying out corrections in the next update.
Best Viewed in Chrome. Best Resolution to view 1280*768 Pixel
Petition: